Skip to Navigation | Skip to Main Content | Skip to Site Map

MyFloridaHouse.gov | Mobile Site

Senate Tracker: Sign Up | Login

The Florida Senate

2021 Florida Statutes (Including 2021B Session)

Title XXXIII REGULATION OF TRADE, COMMERCE, INVESTMENTS, AND SOLICITATIONS
Chapter 558
CONSTRUCTION DEFECTS
CHAPTER 558
CHAPTER 558
CONSTRUCTION DEFECTS
558.001 Legislative findings and declaration.
558.002 Definitions.
558.003 Action; compliance.
558.0035 Design professionals; contractual limitation on liability.
558.004 Notice and opportunity to repair.
558.005 Contract provisions; application.
558.001 Legislative findings and declaration.—The Legislature finds that it is beneficial to have an alternative method to resolve construction disputes that would reduce the need for litigation as well as protect the rights of property owners. An effective alternative dispute resolution mechanism in certain construction defect matters should involve the claimant filing a notice of claim with the contractor, subcontractor, supplier, or design professional that the claimant asserts is responsible for the defect, and should provide the contractor, subcontractor, supplier, or design professional, and the insurer of the contractor, subcontractor, supplier, or design professional, with an opportunity to resolve the claim through confidential settlement negotiations without resort to further legal process.
History.—s. 1, ch. 2003-49; s. 1, ch. 2004-342; s. 1, ch. 2006-281; s. 1, ch. 2015-165.
558.002 Definitions.—As used in this chapter, the term:
(1) “Action” means any civil action or arbitration proceeding for damages or indemnity asserting a claim for damage to or loss of real or personal property caused by an alleged construction defect, but does not include any administrative action or any civil action or arbitration proceeding asserting a claim for alleged personal injuries arising out of an alleged construction defect.
(2) “Association” has the same meaning as in s. 718.103(2), s. 719.103(2), s. 720.301(9), or s. 723.075.
(3) “Claimant” means a property owner, including a subsequent purchaser or association, who asserts a claim for damages against a contractor, subcontractor, supplier, or design professional concerning a construction defect or a subsequent owner who asserts a claim for indemnification for such damages. The term does not include a contractor, subcontractor, supplier, or design professional.
(4) “Completion of a building or improvement” means issuance of a certificate of occupancy, whether temporary or otherwise, that allows for occupancy or use of the entire building or improvement, or an equivalent authorization issued by the governmental body having jurisdiction. In jurisdictions where no certificate of occupancy or equivalent authorization is issued, the term means substantial completion of construction, finishing, and equipping of the building or improvement according to the plans and specifications.
(5) “Construction defect” means a deficiency in, or a deficiency arising out of, the design, specifications, surveying, planning, supervision, observation of construction, or construction, repair, alteration, or remodeling of real property resulting from:
(a) Defective material, products, or components used in the construction or remodeling;
(b) A violation of the applicable codes in effect at the time of construction or remodeling which gives rise to a cause of action pursuant to s. 553.84;
(c) A failure of the design of real property to meet the applicable professional standards of care at the time of governmental approval; or
(d) A failure to construct or remodel real property in accordance with accepted trade standards for good and workmanlike construction at the time of construction.
(6) “Contractor” means any person, as defined in s. 1.01, that is legally engaged in the business of designing, developing, constructing, manufacturing, repairing, or remodeling real property.
(7) “Design professional” means a person, as defined in s. 1.01, who is licensed in this state as an architect, a landscape architect, an engineer, a surveyor, or a geologist or who is a registered interior designer, as defined in s. 481.203.
(8) “Real property” or “property” means land that is improved and the improvements on such land, including fixtures, manufactured housing, or mobile homes and excluding public transportation projects.
(9) “Service” means delivery by certified mail with a United States Postal Service record of evidence of delivery or attempted delivery to the last known address of the addressee, by hand delivery, or by delivery by any courier with written evidence of delivery.
(10) “Subcontractor” means a person, as defined in s. 1.01, who is a contractor who performs labor and supplies material on behalf of another contractor in the construction or remodeling of real property.
(11) “Supplier” means a person, as defined in s. 1.01, who provides only materials, equipment, or other supplies for the construction or remodeling of real property.
History.—s. 2, ch. 2003-49; s. 2, ch. 2004-342; s. 31, ch. 2004-345; s. 27, ch. 2004-353; s. 109, ch. 2005-2; s. 2, ch. 2006-281; s. 1, ch. 2009-203; s. 1, ch. 2013-28; s. 2, ch. 2015-165; s. 82, ch. 2020-160.
558.003 Action; compliance.—A claimant may not file an action subject to this chapter without first complying with the requirements of this chapter. If a claimant files an action alleging a construction defect without first complying with the requirements of this chapter, on timely motion by a party to the action the court shall stay the action, without prejudice, and the action may not proceed until the claimant has complied with such requirements. The notice requirement is not intended to interfere with an owner’s ability to complete a project that has not been substantially completed. The notice is not required for a project that has not reached the stage of completion of the building or improvement.
History.—s. 3, ch. 2003-49; s. 3, ch. 2004-342; s. 2, ch. 2009-203.
558.0035 Design professionals; contractual limitation on liability.—
(1) A design professional employed by a business entity or an agent of the business entity is not individually liable for damages resulting from negligence occurring within the course and scope of a professional services contract if:
(a) The contract is made between the business entity and a claimant or with another entity for the provision of professional services to the claimant;
(b) The contract does not name as a party to the contract the individual employee or agent who will perform the professional services;
(c) The contract includes a prominent statement, in uppercase font that is at least 5 point sizes larger than the rest of the text, that, pursuant to this section, an individual employee or agent may not be held individually liable for negligence;
(d) The business entity maintains any professional liability insurance required under the contract; and
(e) Any damages are solely economic in nature and the damages do not extend to personal injuries or property not subject to the contract.
(2) As used in this section, the term “business entity” means any corporation, limited liability company, partnership, limited partnership, proprietorship, firm, enterprise, franchise, association, self-employed individual, or trust, whether fictitiously named or not, doing business in this state.
History.—s. 2, ch. 2013-28.
558.004 Notice and opportunity to repair.—
(1)(a) In actions brought alleging a construction defect, the claimant shall, at least 60 days before filing any action, or at least 120 days before filing an action involving an association representing more than 20 parcels, serve written notice of claim on the contractor, subcontractor, supplier, or design professional, as applicable, which notice shall refer to this chapter. If the construction defect claim arises from work performed under a contract, the written notice of claim must be served on the person with whom the claimant contracted.
(b) The notice of claim must describe in reasonable detail the nature of each alleged construction defect and, if known, the damage or loss resulting from the defect. Based upon at least a visual inspection by the claimant or its agents, the notice of claim must identify the location of each alleged construction defect sufficiently to enable the responding parties to locate the alleged defect without undue burden. The claimant has no obligation to perform destructive or other testing for purposes of this notice.
(c) The claimant shall endeavor to serve the notice of claim within 15 days after discovery of an alleged defect, but the failure to serve notice of claim within 15 days does not bar the filing of an action, subject to s. 558.003. This subsection does not preclude a claimant from filing an action sooner than 60 days, or 120 days as applicable, after service of written notice as expressly provided in subsection (6), subsection (7), or subsection (8).
(d) A notice of claim served pursuant to this chapter shall not toll any statute of repose period under chapter 95.
(2) Within 30 days after service of the notice of claim, or within 50 days after service of the notice of claim involving an association representing more than 20 parcels, the person served with the notice of claim under subsection (1) is entitled to perform a reasonable inspection of the property or of each unit subject to the claim to assess each alleged construction defect. An association’s right to access property for either maintenance or repair includes the authority to grant access for the inspection. The claimant shall provide the person served with notice under subsection (1) and such person’s contractors or agents reasonable access to the property during normal working hours to inspect the property to determine the nature and cause of each alleged construction defect and the nature and extent of any repairs or replacements necessary to remedy each defect. The person served with notice under subsection (1) shall reasonably coordinate the timing and manner of any and all inspections with the claimant to minimize the number of inspections. The inspection may include destructive testing by mutual agreement under the following reasonable terms and conditions:
(a) If the person served with notice under subsection (1) determines that destructive testing is necessary to determine the nature and cause of the alleged defects, such person shall notify the claimant in writing.
(b) The notice shall describe the destructive testing to be performed, the person selected to do the testing, the estimated anticipated damage and repairs to or restoration of the property resulting from the testing, the estimated amount of time necessary for the testing and to complete the repairs or restoration, and the financial responsibility offered for covering the costs of repairs or restoration.
(c) If the claimant promptly objects to the person selected to perform the destructive testing, the person served with notice under subsection (1) shall provide the claimant with a list of three qualified persons from which the claimant may select one such person to perform the testing. The person selected to perform the testing shall operate as an agent or subcontractor of the person served with notice under subsection (1) and shall communicate with, submit any reports to, and be solely responsible to the person served with notice.
(d) The testing shall be done at a mutually agreeable time.
(e) The claimant or a representative of the claimant may be present to observe the destructive testing.
(f) The destructive testing shall not render the property uninhabitable.
(g) There shall be no construction lien rights under part I of chapter 713 for the destructive testing caused by a person served with notice under subsection (1) or for restoring the area destructively tested to the condition existing prior to testing, except to the extent the owner contracts for the destructive testing or restoration.

If the claimant refuses to agree and thereafter permit reasonable destructive testing, the claimant shall have no claim for damages which could have been avoided or mitigated had destructive testing been allowed when requested and had a feasible remedy been promptly implemented.

(3) Within 10 days after service of the notice of claim, or within 30 days after service of the notice of claim involving an association representing more than 20 parcels, the person served with notice under subsection (1) may serve a copy of the notice of claim to each contractor, subcontractor, supplier, or design professional whom it reasonably believes is responsible for each defect specified in the notice of claim and shall note the specific defect for which it believes the particular contractor, subcontractor, supplier, or design professional is responsible. The notice described in this subsection may not be construed as an admission of any kind. Each such contractor, subcontractor, supplier, and design professional may inspect the property as provided in subsection (2).
(4) Within 15 days after service of a copy of the notice of claim pursuant to subsection (3), or within 30 days after service of the copy of the notice of claim involving an association representing more than 20 parcels, the contractor, subcontractor, supplier, or design professional must serve a written response to the person who served a copy of the notice of claim. The written response must include a report, if any, of the scope of any inspection of the property and the findings and results of the inspection. The written response must include one or more of the offers or statements specified in paragraphs (5)(a)-(e), as chosen by the responding contractor, subcontractor, supplier, or design professional, with all of the information required for that offer or statement.
(5) Within 45 days after service of the notice of claim, or within 75 days after service of a copy of the notice of claim involving an association representing more than 20 parcels, the person who was served the notice under subsection (1) must serve a written response to the claimant. The response shall be served to the attention of the person who signed the notice of claim, unless otherwise designated in the notice of claim. The written response must provide:
(a) A written offer to remedy the alleged construction defect at no cost to the claimant, a detailed description of the proposed repairs necessary to remedy the defect, and a timetable for the completion of such repairs;
(b) A written offer to compromise and settle the claim by monetary payment, that will not obligate the person’s insurer, and a timetable for making payment;
(c) A written offer to compromise and settle the claim by a combination of repairs and monetary payment, that will not obligate the person’s insurer, that includes a detailed description of the proposed repairs and a timetable for the completion of such repairs and making payment;
(d) A written statement that the person disputes the claim and will not remedy the defect or compromise and settle the claim; or
(e) A written statement that a monetary payment, including insurance proceeds, if any, will be determined by the person’s insurer within 30 days after notification to the insurer by means of serving the claim, which service shall occur at the same time the claimant is notified of this settlement option, which the claimant may accept or reject. A written statement under this paragraph may also include an offer under paragraph (c), but such offer shall be contingent upon the claimant also accepting the determination of the insurer whether to make any monetary payment in addition thereto. If the insurer for the person served with the claim makes no response within the 30 days following service, then the claimant shall be deemed to have met all conditions precedent to commencing an action.
(6) If the person served with a notice of claim pursuant to subsection (1) disputes the claim and will neither remedy the defect nor compromise and settle the claim, or does not respond to the claimant’s notice of claim within the time provided in subsection (5), the claimant may, without further notice, proceed with an action against that person for the claim described in the notice of claim. Nothing in this chapter shall be construed to preclude a partial settlement or compromise of the claim as agreed to by the parties and, in that event, the claimant may, without further notice, proceed with an action on the unresolved portions of the claim.
(7) A claimant who receives a timely settlement offer must accept or reject the offer by serving written notice of such acceptance or rejection on the person making the offer within 45 days after receiving the settlement offer. If a claimant initiates an action without first accepting or rejecting the offer, the court shall stay the action upon timely motion until the claimant complies with this subsection.
(8) If the claimant timely and properly accepts the offer to repair an alleged construction defect, the claimant shall provide the offeror and the offeror’s agents reasonable access to the claimant’s property during normal working hours to perform the repair by the agreed-upon timetable as stated in the offer. If the offeror does not make the payment or repair the defect within the agreed time and in the agreed manner, except for reasonable delays beyond the control of the offeror, including, but not limited to, weather conditions, delivery of materials, claimant’s actions, or issuance of any required permits, the claimant may, without further notice, proceed with an action against the offeror based upon the claim in the notice of claim. If the offeror makes payment or repairs the defect within the agreed time and in the agreed manner, the claimant is barred from proceeding with an action for the claim described in the notice of claim or as otherwise provided in the accepted settlement offer.
(9) This section does not prohibit or limit the claimant from making any necessary emergency repairs to the property as are required to protect the health, safety, and welfare of the claimant. In addition, any offer or failure to offer pursuant to subsection (5) to remedy an alleged construction defect or to compromise and settle the claim by monetary payment does not constitute an admission of liability with respect to the defect and is not admissible in an action brought under this chapter.
(10) A claimant’s service of the written notice of claim under subsection (1) tolls the applicable statute of limitations relating to any person covered by this chapter and any bond surety until the later of:
(a) Ninety days, or 120 days, as applicable, after service of the notice of claim pursuant to subsection (1); or
(b) Thirty days after the end of the repair period or payment period stated in the offer, if the claimant has accepted the offer. By stipulation of the parties, the period may be extended and the statute of limitations is tolled during the extension.
(11) The procedures in this chapter apply to each alleged construction defect. However, a claimant may include multiple defects in one notice of claim. The initial list of construction defects may be amended by the claimant to identify additional or new construction defects as they become known to the claimant. The court shall allow the action to proceed to trial only as to alleged construction defects that were noticed and for which the claimant has complied with this chapter and as to construction defects reasonably related to, or caused by, the construction defects previously noticed. Nothing in this subsection shall preclude subsequent or further actions.
(12) This chapter does not:
(a) Bar or limit any rights, including the right of specific performance to the extent such right would be available in the absence of this chapter, any causes of action, or any theories on which liability may be based, except as specifically provided in this chapter;
(b) Bar or limit any defense, or create any new defense, except as specifically provided in this chapter; or
(c) Create any new rights, causes of action, or theories on which liability may be based.
(13) This section does not relieve the person who is served a notice of claim under subsection (1) from complying with all contractual provisions of any liability insurance policy as a condition precedent to coverage for any claim under this section. However, notwithstanding the foregoing or any contractual provision, the providing of a copy of such notice to the person’s insurer, if applicable, shall not constitute a claim for insurance purposes unless the terms of the policy specify otherwise. Nothing in this section shall be construed to impair technical notice provisions or requirements of the liability policy or alter, amend, or change existing Florida law relating to rights between insureds and insurers except as otherwise specifically provided herein.
(14) To the extent that an arbitration clause in a contract for the sale, design, construction, or remodeling of real property conflicts with this section, this section shall control.
(15) Upon request, the claimant and any person served with notice pursuant to subsection (1) shall exchange, within 30 days after service of a written request, which request must cite this subsection and include an offer to pay the reasonable costs of reproduction, any design plans, specifications, and as-built plans; photographs and videos of the alleged construction defect identified in the notice of claim; expert reports that describe any defect upon which the claim is made; subcontracts; purchase orders for the work that is claimed defective or any part of such materials; and maintenance records and other documents related to the discovery, investigation, causation, and extent of the alleged defect identified in the notice of claim and any resulting damages. A party may assert any claim of privilege recognized under the laws of this state with respect to any of the disclosure obligations specified in this chapter. In the event of subsequent litigation, any party who failed to provide the requested materials shall be subject to such sanctions as the court may impose for a discovery violation. Expert reports exchanged between the parties may not be used in any subsequent litigation for any purpose, unless the expert, or a person affiliated with the expert, testifies as a witness or the report is used or relied upon by an expert who testifies on behalf of the party for whom the report was prepared.
History.—s. 4, ch. 2003-49; s. 4, ch. 2004-342; s. 110, ch. 2005-2; s. 3, ch. 2006-281; s. 3, ch. 2009-203; s. 3, ch. 2015-165; s. 8, ch. 2019-75.
558.005 Contract provisions; application.—
(1) Unless a claimant and a potential defendant have agreed in writing to opt out of the requirements of this section, the provisions of this chapter shall apply to any claim for legal relief for which the agreement to make the improvement was made after October 1, 2009, and for which the basis of the claim is a construction defect that has arisen after completion of a building or improvement.
(2) For a claim of a construction defect pursuant to contracts for improvement entered into as described in this subsection, the following applicable notices are required:
(a) Between July 1, 2004, and September 30, 2006, which contract contains the notice as set forth in paragraph (3)(a) and is conspicuously set forth in capitalized letters.
(b) Between October 1, 2006, and September 30, 2009, which contract contains the notice set forth in paragraph (3)(b) and is conspicuously set forth in capitalized letters.
(3)(a) The notice required by paragraph (2)(a) must be in substantially the following form:

CHAPTER 558 NOTICE OF CLAIM

CHAPTER 558, FLORIDA STATUTES, CONTAINS IMPORTANT REQUIREMENTS YOU MUST FOLLOW BEFORE YOU MAY BRING ANY LEGAL ACTION FOR AN ALLEGED CONSTRUCTION DEFECT IN YOUR HOME. SIXTY DAYS BEFORE YOU BRING ANY LEGAL ACTION, YOU MUST DELIVER TO THE OTHER PARTY TO THIS CONTRACT A WRITTEN NOTICE, REFERRING TO CHAPTER 558, OF ANY CONSTRUCTION CONDITIONS YOU ALLEGE ARE DEFECTIVE AND PROVIDE SUCH PERSON THE OPPORTUNITY TO INSPECT THE ALLEGED CONSTRUCTION DEFECTS AND TO CONSIDER MAKING AN OFFER TO REPAIR OR PAY FOR THE ALLEGED CONSTRUCTION DEFECTS. YOU ARE NOT OBLIGATED TO ACCEPT ANY OFFER WHICH MAY BE MADE. THERE ARE STRICT DEADLINES AND PROCEDURES UNDER THIS FLORIDA LAW WHICH MUST BE MET AND FOLLOWED TO PROTECT YOUR INTERESTS.

(b) The notice required by paragraph (2)(b) must expressly cite this chapter and be in substantially the following form:

CHAPTER 558 NOTICE OF CLAIM

CHAPTER 558, FLORIDA STATUTES, CONTAINS IMPORTANT REQUIREMENTS YOU MUST FOLLOW BEFORE YOU MAY BRING ANY LEGAL ACTION FOR AN ALLEGED CONSTRUCTION DEFECT. SIXTY DAYS BEFORE YOU BRING ANY LEGAL ACTION, YOU MUST DELIVER TO THE OTHER PARTY TO THIS CONTRACT A WRITTEN NOTICE, REFERRING TO CHAPTER 558, OF ANY CONSTRUCTION CONDITIONS YOU ALLEGE ARE DEFECTIVE AND PROVIDE SUCH PERSON THE OPPORTUNITY TO INSPECT THE ALLEGED CONSTRUCTION DEFECTS AND TO CONSIDER MAKING AN OFFER TO REPAIR OR PAY FOR THE ALLEGED CONSTRUCTION DEFECTS. YOU ARE NOT OBLIGATED TO ACCEPT ANY OFFER WHICH MAY BE MADE. THERE ARE STRICT DEADLINES AND PROCEDURES UNDER THIS FLORIDA LAW WHICH MUST BE MET AND FOLLOWED TO PROTECT YOUR INTERESTS.

(4) At any time, a claimant and the person to whom notice is served or otherwise must be served under s. 558.004(1) may agree in writing to preaction mediation or otherwise alter the procedure for the notice of claim process described in this chapter.
(5) Notwithstanding the notice requirements of this section for contracts entered into on or after October 1, 2006, this chapter applies to all actions accruing before July 1, 2004, but not yet commenced as of July 1, 2004, and failure to include such notice requirements in a contract entered into before July 1, 2004, does not operate to bar the procedures of this chapter from applying to all such actions.
(6) Notwithstanding s. 558.003, unless the parties agree that this chapter does not apply, after October 1, 2009, any written contract for improvement of real property entered into between an owner and a contractor, or between an owner and a design professional, must contain substantially the following notice: “ANY CLAIMS FOR CONSTRUCTION DEFECTS ARE SUBJECT TO THE NOTICE AND CURE PROVISIONS OF CHAPTER 558, FLORIDA STATUTES.” The failure to include in the contract the notice provided in this subsection does not subject the contracting owner, contractor, or design professional to any penalty. The purpose of the contractual notice is to promote awareness of the procedure, not to be a penalty.
History.—s. 5, ch. 2003-49; s. 5, ch. 2004-342; s. 4, ch. 2006-281; s. 4, ch. 2009-203.