Quick Links
- General Laws Conversion Table (2024) [PDF]
- Florida Statutes Definitions Index (2024) [PDF]
- Table of Section Changes (2024) [PDF]
- Preface to the Florida Statutes (2024) [PDF]
- Table Tracing Session Laws to Florida Statutes (2024) [PDF]
- Index to Special and Local Laws (1971-2024) [PDF]
- Index to Special and Local Laws (1845-1970) [PDF]
- Statute Search Tips
2023 Florida Statutes (including 2023C)
Chapter 337
CONTRACTING; ACQUISITION, DISPOSAL, AND USE OF PROPERTY
CONTRACTING; ACQUISITION, DISPOSAL, AND USE OF PROPERTY
CHAPTER 337
CONTRACTING; ACQUISITION, DISPOSAL, AND USE OF PROPERTY
337.015 Administration of public contracts.
337.02 Purchases by department subject to competitive bids; advertisement; emergency purchases; bid specifications.
337.023 Sale of building; acceptance of replacement building.
337.025 Innovative transportation projects; department to establish program.
337.026 Authority of department to enter into agreements for construction aggregate materials.
337.0261 Construction aggregate materials.
337.02611 Phosphogypsum as a construction aggregate material; study.
337.0262 Purchase and use of clay, peat, gravel, sand, or any other solid substance extracted from borrow pits.
337.027 Authority to implement a business development program.
337.03 Authority of department to purchase surplus properties from the Federal Government.
337.105 Qualifications of professional consultants and other providers of contractual services; performance bonds; and audits of indirect costs.
337.106 Professional service providers; requirement for professional liability insurance.
337.107 Contracts for right-of-way services.
337.1075 Contracts for planning services.
337.108 Hazardous materials and pollutants; indemnification.
337.11 Contracting authority of department; bids; emergency repairs, supplemental agreements, and change orders; combined design and construction contracts; progress payments; records; requirements of vehicle registration.
337.1101 Contracting and procurement authority of the department; settlements; notification required.
337.111 Contracting for monuments and memorials to military veterans at rest areas.
337.125 Socially and economically disadvantaged business enterprises; notice requirements.
337.135 Socially and economically disadvantaged business enterprises; punishment for false representation.
337.139 Efforts to encourage awarding contracts to disadvantaged business enterprises.
337.14 Application for qualification; certificate of qualification; restrictions; request for hearing.
337.141 Payment of construction or maintenance contracts.
337.145 Offsetting payments.
337.16 Disqualification of delinquent contractors from bidding; determination of contractor nonresponsibility; denial, suspension, and revocation of certificates of qualification; grounds; hearing.
337.162 Professional services.
337.164 Legislative intent with respect to integrity of public contracting process.
337.165 Contract crime; denial or revocation of a certificate of qualification.
337.166 Moneys recovered for violations of antitrust laws.
337.167 Administrative procedures; stays and injunctions.
337.168 Confidentiality of official estimates and bid analysis and monitoring system.
337.169 Effect of ch. 83-4 on existing remedies.
337.17 Bid guaranty.
337.175 Retainage.
337.18 Surety bonds for construction or maintenance contracts; requirement with respect to contract award; bond requirements; defaults; damage assessments.
337.185 State Arbitration Board.
337.19 Suits by and against department; limitation of actions; forum.
337.195 Limits on liability.
337.221 Claims settlement process.
337.242 Acquisition of rail corridors.
337.243 Notification of land use changes in designated transportation corridors.
337.25 Acquisition, lease, and disposal of real and personal property.
337.2505 Donations for landscape projects.
337.251 Lease of property for joint public-private development and areas above or below department property.
337.26 Execution and effect of instruments of sale, lease, or conveyance executed by department.
337.27 Exercise of power of eminent domain by department; procedure; title; cost.
337.273 Transportation corridors.
337.2735 Recording of municipal maps of reservation for transportation corridors and transportation facilities; establishment of building setback lines; restrictions on issuance of development permits; hearings.
337.274 Authority of department agent or employee to enter lands, waters, and premises of another in the performance of duties.
337.276 Issuance of bonds for right-of-way land acquisition and state bridge construction.
337.29 Vesting of title to roads; liability for torts.
337.401 Use of right-of-way for utilities subject to regulation; permit; fees.
337.402 Damage to public road caused by utility.
337.403 Interference caused by utility; expenses.
337.404 Removal or relocation of utility facilities; notice and order; court review.
337.405 Trees or other vegetation within rights-of-way of State Highway System or publicly owned rail corridors; removal or damage; penalty.
337.406 Unlawful use of state transportation facility right-of-way; penalties.
337.4061 Definitions; unlawful use of state-maintained road right-of-way by nonfranchised cable and video services.
337.407 Regulation of signs and lights within rights-of-way.
337.408 Regulation of bus stops, benches, transit shelters, street light poles, waste disposal receptacles, and modular news racks within rights-of-way.
337.409 Willfully or maliciously removing, damaging, destroying, altering, or appropriating benches, transit shelters, waste receptacles, or advertising displayed thereon; penalty.
337.015 Administration of public contracts.—Recognizing that the inefficient and ineffective administration of public contracts inconveniences the traveling public, increases costs to taxpayers, and interferes with commerce, the Legislature hereby determines and declares that:
(1) Time is an essential element of the contract, and to assure satisfactory work progress and timely contract completion, the department shall minimize the allowance of additional contract time.
(2) In order to increase competition and maximize the utilization of personnel, the department shall minimize the variances between contract lettings.
(3) To protect the public interest, the department shall vigorously pursue claims against contractors and consultants for time overruns and substandard work products.
(4) The department shall stabilize the work program, ensuring the timely and systematic completion of projects.
(5) To encourage increased competition and timely completion of construction projects, the department may allow flexible start and finish time limits when the commencement of work is not essential to the public health, safety, or welfare. When using flexible start and finish time limits, the department may withhold up to 10 percent retainage on completed work when the contractor either fails to timely commence work or falls behind in work progress at any point prior to completion of the contract.
(6) The department shall make payments for road and bridge construction and maintenance work throughout the month so that the cash balance fluctuates as little as practicable.
History.—s. 3, ch. 87-100; s. 11, ch. 89-301; s. 126, ch. 92-152; s. 12, ch. 94-237; s. 83, ch. 99-385.
337.02 Purchases by department subject to competitive bids; advertisement; emergency purchases; bid specifications.—
(1) Except as provided herein, purchase by the Department of Transportation of commodities, including the advertising and awarding of competitive bids, shall be governed by chapters 283 and 287 and rules adopted by the Department of Management Services pursuant thereto. However, the provisions of s. 287.057 notwithstanding, the department may purchase parts and repairs valued at up to the threshold amount provided in s. 287.017 for CATEGORY TWO for the repair of mobile road maintenance equipment, marine vessels, permanent vehicle scales, and mechanical and electrical equipment for movable bridges, toll facilities including the Florida Turnpike, and up to the threshold amount provided in s. 287.017 for CATEGORY THREE for treatment plants and lift stations for water and sewage, and major heating and cooling systems without receiving competitive bids.
(2) If the department determines that an emergency exists in regard to the purchase of materials, machinery, tools, equipment, or supplies, so that the delay incident to giving opportunity for competitive bidding would be detrimental to the interests of the state, the provisions for competitive bidding do not apply; and the department may authorize or purchase such materials, machinery, tools, equipment, or supplies without giving opportunity for competitive bidding thereon. The department shall, within 10 days after such determination and purchase, file with the head of the Department of Management Services a written statement of the materials, machinery, tools, equipment, or supplies purchased and a certificate as to the conditions and circumstances constituting such emergency.
(3) When the department advertises for bids on a contract for supplies, materials, equipment, or other items needed by the department, specifications shall be drafted in such manner as will afford adequate protection to the state as to quality and performance, but specifications shall not be drafted in any manner which will preclude competition in bidding.
History.—s. 81, ch. 29965, 1955; s. 5, ch. 67-461; ss. 23, 35, ch. 69-106; s. 112, ch. 71-377; s. 134, ch. 84-309; s. 18, ch. 85-180; s. 29, ch. 90-268; s. 281, ch. 92-279; s. 55, ch. 92-326; s. 33, ch. 96-323.
337.023 Sale of building; acceptance of replacement building.—Notwithstanding the provisions of s. 216.292(4)(c), if the department sells a building, the department may accept the construction of a replacement building, in response to a request for proposals, totally or partially in lieu of cash, and may do so without a specific legislative appropriation. Such action is subject to the approval of the Executive Office of the Governor, and is subject to the notice, review, and objection procedures under s. 216.177. The replacement building shall be consistent with the current and projected needs of the department as agreed upon by the department and the Department of Management Services.
History.—s. 51, ch. 97-278; s. 121, ch. 99-13; s. 55, ch. 2000-371; s. 46, ch. 2005-152; s. 72, ch. 2023-8.
337.025 Innovative transportation projects; department to establish program.—
(1) The department may establish a program for transportation projects demonstrating innovative techniques of highway and bridge design, construction, maintenance, and finance which have the intended effect of measuring resiliency and structural integrity and controlling time and cost increases on construction projects. Such techniques may include, but are not limited to, state-of-the-art technology for pavement, safety, and other aspects of highway and bridge design, construction, and maintenance; innovative bidding and financing techniques; accelerated construction procedures; and those techniques that have the potential to reduce project life cycle costs. To the maximum extent practical, the department must use the existing process to award and administer construction and maintenance contracts. When specific innovative techniques are to be used, the department is not required to adhere to those provisions of law that would prevent, preclude, or in any way prohibit the department from using the innovative technique. However, before using an innovative technique that is inconsistent with another provision of law, the department must document in writing the need for the exception and identify what benefits the traveling public and the affected community are anticipated to receive. The department may enter into no more than $200 million in contracts awarded annually for the purposes authorized by this section.
(2) The annual cap on contracts provided in subsection (1) does not apply to turnpike enterprise projects.
History.—s. 34, ch. 96-323; s. 45, ch. 99-385; s. 10, ch. 2000-266; s. 9, ch. 2002-20; s. 2, ch. 2009-89; s. 3, ch. 2019-153; s. 9, ch. 2019-169; s. 8, ch. 2021-188; s. 10, ch. 2023-70.
337.026 Authority of department to enter into agreements for construction aggregate materials.—
(1) The department may pursue procurement techniques that will provide the department with reliable and economic supplies of construction aggregate materials and control time and cost increases on construction projects.
(2) The department may enter into agreements with private or public entities. Such agreements may include, but are not limited to, department acquisition of materials or resources or long-term leases for a term not to exceed 99 years that will advance the state’s transportation needs.
(3) To the maximum extent practical, the department must use the existing process to award and administer such procurement techniques. When techniques authorized by this section are to be used, the department is not required to adhere to provisions of law that would prevent, preclude, or prohibit it from using this procurement technique. However, prior to using this procurement technique, the department must document in writing the need for the exception and identify the benefits the traveling public and the affected community are anticipated to receive.
History.—s. 31, ch. 2007-196.
337.0261 Construction aggregate materials.—
(1) DEFINITIONS.—“Construction aggregate materials” means crushed stone, limestone, dolomite, limerock, shell rock, cemented coquina, sand for use as a component of mortars, concrete, bituminous mixtures, or underdrain filters, and other mined resources providing the basic material for concrete, asphalt, and road base.
(2) LEGISLATIVE INTENT.—The Legislature finds that there is a strategic and critical need for an available supply of construction aggregate materials within the state and that a disruption of the supply would cause a significant detriment to the state’s construction industry, transportation system, and overall health, safety, and welfare. In addition, the Legislature recognizes that construction aggregate materials mining is an industry of critical importance to the state and that the mining of construction aggregate materials is in the public interest.
(3) LOCAL GOVERNMENT DECISIONMAKING.—A local government may not approve or deny a proposed land use zoning change, comprehensive plan amendment, land use permit, ordinance, or order regarding construction aggregate materials without considering any information provided by the Department of Transportation regarding the effect such change, amendment, permit decision, ordinance, or order would have on the availability, transportation, cost, and potential extraction of construction aggregate materials on the local area, the region, and the state. The failure of the Department of Transportation to provide this information shall not be a basis for delay or invalidation of the local government action. A local government may not impose a moratorium, or combination of moratoria, of more than 12 months’ duration on the mining or extraction of construction aggregate materials, commencing on the date the vote was taken to impose the moratorium. January 1, 2007, shall serve as the commencement of the 12-month period for moratoria already in place as of July 1, 2007.
(4) EXPEDITED PERMITTING.—Due to the state’s critical infrastructure needs and the potential shortfall in available construction aggregate materials, limerock environmental resource permitting and reclamation applications filed after March 1, 2007, are eligible for the expedited permitting processes contained in s. 403.973. Challenges to state agency action in the expedited permitting process for establishment of a limerock mine in this state under s. 403.973 are subject to the same requirements as challenges brought under s. 403.973(14)(a), except that, notwithstanding s. 120.574, summary proceedings must be conducted within 30 days after a party files the motion for summary hearing, regardless of whether the parties agree to the summary proceeding.
History.—s. 30, ch. 2007-196; s. 67, ch. 2008-4; s. 3, ch. 2009-89; s. 65, ch. 2010-5; s. 39, ch. 2016-239.
337.02611 Phosphogypsum as a construction aggregate material; study.—
(1) The department shall conduct a study to evaluate the suitability of using phosphogypsum as a construction aggregate material as defined in s. 337.0261(1). The department may consider any prior or ongoing studies of phosphogypsum’s road suitability in the fulfillment of this duty. The study and a determination of suitability must be completed by April 1, 2024.
(2) Upon a determination of suitability by the department, phosphogypsum from phosphate production may be used as a construction aggregate material in accordance with the conditions of the United States Environmental Protection Agency approval for the use.
History.—s. 2, ch. 2023-311.
337.0262 Purchase and use of clay, peat, gravel, sand, or any other solid substance extracted from borrow pits.—
(1) The department, and any contractor or subcontractor of the department, may not purchase or use any clay, peat, gravel, sand, or other solid substance extracted from a borrow pit as defined in s. 378.403 unless:
(a) Certification is provided to the department, contractor, or subcontractor by the operator of the borrow pit that it is in compliance with the notice requirements and substantive requirements of s. 378.801; and
(b) The operator of the borrow pit is in compliance with the performance standards in s. 378.803, including, but not limited to, providing proof of currently valid permits required by the Department of Environmental Protection and the appropriate water management district.
(2) All contracts and purchase orders executed by the department, and all subcontracts and purchase orders executed by contractors or subcontractors after July 1, 2021, must include specific requirements for compliance with this section.
(3) In the event that the department determines that substances are being obtained and used from a borrow pit that is not in compliance with this section, the department must cease to accept any substances from that borrow pit within 48 hours after such determination. The department may resume acceptance of substances from the borrow pit once the borrow pit is in compliance with this section.
History.—s. 9, ch. 2021-188.
337.027 Authority to implement a business development program.—
(1) The department may establish a program for highway projects which would assist small businesses. The purpose of this program is to increase competition, lower prices, and provide increased support to meet the department’s future work program. The program may include, but is not limited to, setting aside contracts, providing preference points for the use of small businesses, providing special assistance in bidding and contract completion, waiving bond requirements, and implementing other strategies that would increase competition.
(2) For purposes of this section, the term “small business” means a business with yearly average gross receipts of less than $15 million for road and bridge contracts and less than $6.5 million for professional and nonprofessional services contracts. A business’ average gross receipts is determined by averaging its annual gross receipts over the last 3 years, including the receipts of any affiliate as defined in s. 337.165.
(3) The department may adopt rules to implement this section.
History.—s. 12, ch. 2016-181.
337.03 Authority of department to purchase surplus properties from the Federal Government.—
(1) The department is authorized to purchase from the Federal Government any supplies, material, equipment, appliances, or other property at such price and upon such terms as may in the judgment of the department be proper, without first advertising for bids, regardless of the value of, or the price paid for, such property; provided the price paid for such supplies, materials, equipment, appliances, or other property does not exceed the price for which such property may be purchased upon the open market.
(2) Payment of the cost of all supplies, material, equipment, appliances, or other property purchased pursuant to the authority given in subsection (1) shall be made upon vouchers issued and certified to by the department.
History.—s. 82, ch. 29965, 1955; s. 5, ch. 67-461; ss. 23, 35, ch. 69-106; s. 113, ch. 71-377; s. 100, ch. 77-104; s. 135, ch. 84-309.
337.105 Qualifications of professional consultants and other providers of contractual services; performance bonds; and audits of indirect costs.—
(1) Before the employment of a professional consultant or other provider of service, the department shall make a finding that the person to be employed is fully qualified to render the desired service. Among the factors to be considered in making this finding are the professional reputation, past performance record, and experience of the candidate and the adequacy of the personnel making up his or her organization. The department may, for good cause, deny or suspend for a specified period of time a person or firm from consideration for award of a professional service contract for a particular type of work. The department shall adopt rules to administer this section. As used in this subsection, the term “good cause” includes, but is not limited to, circumstances in which a consultant or other provider of service or its official representative:
(a) Makes or submits false, deceptive, or fraudulent statements in any bid or proposal to the department, in any application for certification of qualification, or in any administrative or judicial proceeding;
(b) Becomes insolvent or is the subject of a bankruptcy petition;
(c) Has been qualified by the department based on a license or registration issued by the state which has subsequently been revoked or suspended or has been denied;
(d) Has been qualified by the department based on the employment of personnel no longer employed by the consultant or other provider of service;
(e) Fails to maintain adequate professional liability insurance for the certified areas of work;
(f) Fails to satisfactorily perform contract requirements;
(g) Wrongfully employs or otherwise provides compensation to any employee or officer of the department, or willfully offers an employee or officer of the department any pecuniary or other benefit, with the intent to influence the employee’s or officer’s official action or judgment;
(h) Is affiliated with a consultant or other provider of service whose qualification to render professional services has been denied or suspended by the department and is dependent upon such consultant or other provider of service for personnel, equipment, or finances; or
(i) Has been barred or suspended from consideration for work with any other governmental entity.
(2) For any contractual service, except a contractual service provided to the department under s. 287.055, the department may require a performance bond equal to the full contract value if such requirement is deemed to be in the best interest of the state.
(3) The department may require providers of professional services acquired under s. 287.055 to submit annual audits of their indirect costs performed in accordance with department guidelines. The department may establish limits on the indirect cost rates it will accept.
History.—s. 1, ch. 70-64; s. 171, ch. 84-309; s. 4, ch. 87-100; s. 1, ch. 89-21; s. 494, ch. 95-148; s. 35, ch. 96-323; s. 2, ch. 98-105.
Note.—Former s. 337.33.
337.106 Professional service providers; requirement for professional liability insurance.—Except for any person or firm providing professional services of a research or training nature, any person or firm rendering legal, architectural, engineering, or other professional services to the department shall have and maintain during the period the services are rendered a professional liability insurance policy or policies with a company or companies authorized to do business in the state affording professional liability coverage for the professional services rendered, in an amount deemed sufficient by the department. The requirement for professional liability insurance set forth in this section may be waived by the department, if the person or firm providing professional services obtains and maintains an unexpired, irrevocable letter of credit, established pursuant to chapter 675, in an amount not less than the minimum insurance coverage required by the contract with the department. The letter of credit shall be solely for the benefit of the department and must remain valid until 3 years after final acceptance of the project of which the professional services were a part. The letter of credit shall be approved by the department comptroller and be payable to the department as beneficiary upon presentment of a final judgment indicating liability and awarding damages to be paid to the department by the professional service provider or upon presentment of a settlement agreement signed by all parties. The letter of credit shall be nonassignable and nontransferable. The letter of credit shall be issued by any bank or savings association organized and existing under the laws of this state or any bank or savings association organized under the laws of the United States that has its principal place of business in this state or has a branch office which is authorized under the laws of this state or of the United States to receive deposits in this state.
History.—s. 3, ch. 70-168; s. 138, ch. 84-309; s. 1, ch. 88-299; s. 51, ch. 90-136; s. 119, ch. 92-152; s. 2, ch. 92-318.
337.107 Contracts for right-of-way services.—The department may enter into contracts pursuant to s. 287.055 for right-of-way services on transportation corridors and transportation facilities. Right-of-way services include negotiation and acquisition services, appraisal services, demolition and removal of improvements, and asbestos-abatement services.
History.—s. 111, ch. 92-152; s. 25, ch. 95-257; ss. 1, 3, ch. 2001-350; ss. 13, 14, ch. 2005-290.
337.1075 Contracts for planning services.—The department may enter into contracts pursuant to s. 287.055 for professional transportation-related planning services to be provided by planners certified by the American Institute of Certified Planners.
History.—s. 14, ch. 93-164.
337.108 Hazardous materials and pollutants; indemnification.—
(1) For purposes of this section:
(a) The term “hazardous materials” shall have the same meaning as provided in s. 768.128(1)(a).
(b) The term “pollutants” shall have the same meaning as provided in s. 376.031.
(c) The term “contractor” means any person or firm having a contract for rendering services to the department relating to the construction or maintenance of a transportation facility; the term does not include persons or firms performing hazardous material or pollutant response, containment, disposal, or cleanup services.
(2) The department may agree to hold harmless and indemnify a contractor for damages when the contractor discovers or encounters hazardous materials or pollutants during the performance of services for the department when the presence of such materials or pollutants was unknown or not reasonably discoverable. Such indemnification agreements shall only be effective if the contractor immediately stops work and notifies the department of the hazardous material or pollutant problem.
(3) Such an indemnification agreement may not indemnify the contractor for damages resulting from any willful, wanton, or intentional conduct of the contractor.
History.—s. 125, ch. 92-152; s. 164, ch. 94-356.
337.11 Contracting authority of department; bids; emergency repairs, supplemental agreements, and change orders; combined design and construction contracts; progress payments; records; requirements of vehicle registration.—
(1) The department shall have authority to enter into contracts for the construction and maintenance of all roads designated as part of the State Highway System or the State Park Road System or of any roads placed under its supervision by law. The department shall also have authority to enter into contracts for the construction and maintenance of rest areas, weigh stations, and other structures, including roads, parking areas, supporting facilities and associated buildings used in connection with such facilities. However, no such contract shall create any third-party beneficiary rights in any person not a party to the contract.
(2) The department shall ensure that all project descriptions, including design plans, are complete, accurate, and up to date prior to the advertisement for bids on such projects.
(3)(a) On all construction contracts of $250,000 or less, and any construction contract of less than $500,000 for which the department has waived prequalification under s. 337.14, the department shall advertise for bids in a newspaper having general circulation in the county where the proposed work is located. Publication shall be at least once a week for no less than 2 consecutive weeks, and the first publication shall be no less than 14 days prior to the date on which bids are to be received.
(b) On all construction contracts greater than $250,000, the department shall provide a bid solicitation notice to all prequalified contractors at least 2 weeks before the date bids are scheduled to be received.
(c) No advertisement for bids shall be published and no bid solicitation notice shall be provided until title to all necessary rights-of-way and easements for the construction of the project covered by such advertisement or notice has vested in the state or a local governmental entity, and all railroad crossing and utility agreements have been executed. The turnpike enterprise is exempt from this paragraph for a turnpike enterprise project. Title to all necessary rights-of-way shall be deemed to have been vested in the State of Florida when such title has been dedicated to the public or acquired by prescription.
(4) The department may award the proposed construction and maintenance work to the lowest responsible bidder, or in the instance of a time-plus-money contract, the lowest evaluated responsible bidder, or it may reject all bids and proceed to rebid the work in accordance with subsection (2) or otherwise perform the work.
(5)(a) Any person who files an action protesting a bid solicitation, a bid rejection, or an award pursuant to this section shall post with the department, at the time of filing a notice of protest, a bond payable to the department in the following amounts:
1. For an action protesting a bid solicitation that requires qualification of bidders, the bond shall be $5,000.
2. For an action protesting a bid rejection or contract award that requires qualification of bidders, the bond shall be equal to 1 percent of the lowest bid submitted or $5,000, whichever is greater.
3. For an action protesting a bid solicitation, bid rejection, or contract award that does not require qualification of bidders, the bond shall be $2,500.
(b) The bond required by this subsection shall be conditioned upon the payment of all costs which may be adjudged against the person filing the protest in the administrative hearing in which the action is brought and any subsequent appellate court proceeding. If, after completion of the administrative hearing process and any appellate court proceedings, the department prevails, it shall recover all costs and charges which shall be included in the final order or judgment, excluding attorney’s fees. Upon payment of such costs and charges by the person filing the protest, the bond shall be returned to him or her. If the person filing the protest prevails, he or she shall recover from the department all costs and charges which shall be included in the final order or judgment, excluding attorney’s fees. The entire amount of the bond shall be forfeited if the administrative law judge determines that a protest was filed for a frivolous or improper purpose, including, but not limited to, the purpose of harassing, causing unnecessary delay, or causing needless cost for the department or parties.
(c) As an alternative to any provision in s. 120.57(3)(c), the department may proceed with the bid solicitation or contract award process when the head of the department sets forth in writing particular facts and circumstances which require the continuance of the bid solicitation process or the contract award process in order to avoid a substantial loss of funding to the state.
(d) A person may not file a protest on any project for which he or she is not certified to bid pursuant to s. 337.14.
(6)(a) If the secretary determines that an emergency in regard to the restoration or repair of any state transportation facility exists such that the delay incident to giving opportunity for competitive bidding would be detrimental to the interests of the state, the provisions for competitive bidding do not apply; and the department may enter into contracts for restoration or repair without giving opportunity for competitive bidding on such contracts. Within 30 days after such determination and contract execution, the head of the department shall file with the Executive Office of the Governor a written statement of the conditions and circumstances constituting such emergency.
(b) If the secretary determines that delays on a contract for maintenance exist due to administrative challenges, bid protests, defaults or terminations and the further delay would reduce safety on the transportation facility or seriously hinder the department’s ability to preserve the state’s investment in that facility, competitive bidding provisions may be waived and the department may enter into a contract for maintenance on the facility. However, contracts for maintenance executed under the provisions of this paragraph shall be interim in nature and shall be limited in duration to a period of time not to exceed the length of the delay necessary to complete the competitive bidding process and have the contract in place.
(c) When the department determines that it is in the best interest of the public for reasons of public concern, economy, improved operations, or safety, and only when circumstances dictate rapid completion of the work, the department may, up to the amount of $500,000, enter into contracts for construction and maintenance without advertising and receiving competitive bids. The department may enter into such contracts only upon a determination that the work is necessary for one of the following reasons:
1. To ensure timely completion of projects or avoidance of undue delay for other projects;
2. To accomplish minor repairs or construction and maintenance activities for which time is of the essence and for which significant cost savings would occur; or
3. To accomplish nonemergency work necessary to ensure avoidance of adverse conditions that affect the safe and efficient flow of traffic.
The department shall make a good faith effort to obtain two or more quotes, if available, from qualified contractors before entering into any contract. The department shall give consideration to disadvantaged business enterprise participation. However, when the work exists within the limits of an existing contract, the department shall make a good faith effort to negotiate and enter into a contract with the prime contractor on the existing contract.
(7)(a) If the department determines that it is in the best interests of the public, the department may combine the design and construction phases of a project into a single contract. Such contract is referred to as a design-build contract.
(b) If the department determines that it is in the best interests of the public, the department may combine the design and construction phases of a project fully funded in the work program into a single contract and select the design-build firm in the early stages of a project to ensure that the design-build firm is part of the collaboration and development of the design as part of a step-by-step progression through construction. Such a contract is referred to as a phased design-build contract. For phased design-build contracts, selection and award must include a two-phase process. For phase one, the department shall competitively award the contract to a design-build firm based upon qualifications. For phase two, the design-build firm shall competitively bid construction trade subcontractor packages and, based upon these bids, negotiate with the department a fixed firm price or guaranteed maximum price that meets the project budget and scope as advertised in the request for qualifications.
(c) Design-build contracts and phased design-build contracts may be advertised and awarded notwithstanding the requirements of paragraph (3)(c). However, construction activities may not begin on any portion of such projects for which the department has not yet obtained title to the necessary rights-of-way and easements for the construction of that portion of the project has vested in the state or a local governmental entity and all railroad crossing and utility agreements have been executed. Title to rights-of-way shall be deemed to have vested in the state when the title has been dedicated to the public or acquired by prescription.
(d) The department shall adopt by rule procedures for administering design-build and phased design-build contracts. Such procedures shall include, but not be limited to:
1. Prequalification requirements.
2. Public announcement procedures.
3. Scope of service requirements.
4. Letters of interest requirements.
5. Short-listing criteria and procedures.
6. Bid proposal requirements.
7. Technical review committee.
8. Selection and award processes.
9. Stipend requirements.
(e) The department must receive at least three letters of interest in order to proceed with a request for proposals. The department shall request proposals from no fewer than three of the design-build firms submitting letters of interest. If a design-build firm withdraws from consideration after the department requests proposals, the department may continue if at least two proposals are received.
(8) If the department determines that it is in the best interest of the public, the department may pay a stipend to nonselected design-build firms that have submitted responsive proposals for construction contracts. The decision and amount of a stipend shall be based upon department analysis of the estimated proposal development costs and the anticipated degree of engineering design during the procurement process. The department retains the right to use those designs from responsive nonselected design-build firms that accept a stipend.
(9)(a) The department shall permit the use of written supplemental agreements, written work orders pursuant to a contingency pay item or contingency supplemental agreement, and written change orders to any contract entered into by the department. Any supplemental agreement shall be reduced to written contract form and executed by the contractor and the department. Any supplemental agreement modifying any item in the original contract must be approved by the head of the department, or his or her designee, and executed by the appropriate person designated by him or her. Any surety issuing a bond under s. 337.18 shall be fully liable under such surety bond to the full extent of any modified contract amount up to and including 25 percent over the original contract amount and without regard to the fact that the surety was not aware of or did not approve such modifications. However, if modifications of the original contract amount cumulatively result in modifications of the contract amount in excess of 25 percent of the original contract amount, the surety’s approval shall be required to bind the surety under the bond on that portion in excess of 25 percent of the original contract amount.
(b) Supplemental agreements and written work orders pursuant to a contingency pay item or contingency supplemental agreement shall be used to clarify the plans and specifications of a contract; to provide for unforeseen work, grade changes, or alterations in plans which could not reasonably have been contemplated or foreseen in the original plans and specifications; to change the limits of construction to meet field conditions; to provide a safe and functional connection to an existing pavement; to settle contract claims; and to make the project functionally operational in accordance with the intent of the original contract. Supplemental agreements may be used to expand the physical limits of a project only to the extent necessary to make the project functionally operational in accordance with the intent of the original contract. The cost of any such agreement extending the physical limits of a project shall not exceed $100,000 or 10 percent of the original contract price, whichever is greater.
(c) Written change orders may be issued by the department and accepted by the contractor covering minor changes in the plans, specifications, or quantities of work within the scope of a contract, when prices for the items of work affected are previously established in the contract, but in no event may such change orders extend the physical limits of the work.
(d) For the purpose of this section, the term “physical limits” means the length or width of any project and specifically includes drainage facilities not running parallel to the project. The length and width of temporary connections affected by such supplemental agreements shall be established in accordance with current engineering practice.
(e) Upon completion and final inspection of the contract work, the department may accept the improvement if it is in substantial compliance with the plans, specifications, special provisions, proposals, and contract and if a proper adjustment in the contract price is made.
(f) Any supplemental agreement or change order in violation of this section is null and void and unenforceable for payment.
(10) The department shall preserve all records which reflect the quantities of materials used in the construction of any road project supervised by the department for a period of 3 years after final acceptance. This requirement is equally binding when materials are purchased by prime contractors or subcontractors.
(11)(a) Every contract let by the department for the performance of work shall contain a provision requiring the prime contractor, before receipt of any progress payment under the provisions of such contract, to certify that the prime contractor has disbursed to all subcontractors and suppliers having an interest in the contract their pro rata shares of the payment out of previous progress payments received by the prime contractor for all work completed and materials furnished in the previous period, less any retainage withheld by the prime contractor pursuant to an agreement with a subcontractor, as approved by the department for payment. The department shall not make any such progress payment before receipt of such certification, unless the contractor demonstrates good cause for not making any such required payment and furnishes written notification of any such good cause to both the department and the affected subcontractors and suppliers.
(b) Every contract let by the department for the performance of work shall contain a provision requiring the prime contractor, within 30 days of receipt of the final progress payment or any other payments received thereafter except the final payment, to pay all subcontractors and suppliers having an interest in the contract their pro rata shares of the payment for all work completed and materials furnished, unless the contractor demonstrates good cause for not making any such required payment and furnishes written notification of any such good cause to both the department and the affected subcontractors or suppliers within such 30-day period.
(c) The department shall document and monitor claims of nonpayment of prime contractors, subcontractors, and suppliers. The claims shall be submitted to the department in writing, and the department shall maintain, in a central file, a record of each claim, specifying the claimant and the nature and the resolution of the claim.
(12) Notwithstanding any other provision of law to the contrary, the department has unilateral authority to pay the contractor the sums the department determines to be due to the contractor for work performed on a project. This unilateral authority to pay by the department does not preclude or limit the rights of the department and the contractor to negotiate and agree to the amounts to be paid to the contractor. By acceptance of any such unilateral payment, the contractor does not waive any rights the contractor may have against the department for payment of any additional sums the contractor claims are due for the work.
(13) Each contract let by the department for the performance of road or bridge construction or maintenance work shall require all motor vehicles that the contractor operates or causes to be operated in this state to be registered in compliance with chapter 320.
(14) Each contract let by the department for performance of road or bridge construction or maintenance work must contain a traffic maintenance plan which shows the appropriate regulatory speed signs and traffic control devices for the work zone area as defined in s. 316.003.
(15) Each contract let by the department for performance of bridge construction or maintenance over navigable waters must contain a provision requiring marine general liability insurance, in an amount to be determined by the department, which covers third-party personal injury and property damage caused by vessels used by the contractor in the performance of the work.
(16) The department shall implement strategies to reduce the cost of all project phases, including design, construction, and inspection, while ensuring that the design and construction of projects meet applicable federal and state standards. The department shall make a record of such strategies and the projected savings related thereto.
(17) The department may share a portion of the construction cost savings realized due to a change in the construction contract design and scope, initiated after execution of the contract, with a design services consultant or a construction engineering and inspection services consultant to the extent that the consultant’s input and involvement contributed to such savings. The amount paid to a consultant pursuant to this subsection may not exceed 10 percent of the construction cost savings realized.
(18) When the department determines that it is in the best interest of the public, the department may enter into a contract with an electric utility as defined in s. 366.02(4) for the construction or maintenance of lighting on poles owned by the electric utility and located within a road right-of-way without competitive bidding. In any contract entered into without competition, the individuals taking part in the evaluation or award process shall attest in writing that they are independent of, and have no conflict of interest in, the entities evaluated and selected.
(19) The department shall have the authority to develop procedures for the administration of maintenance contracts. In addition to the other contract administration matters, the procedures shall address advertising and bid solicitation for maintenance contracts and each bid solicitation notice shall contain specific requirements, if any are deemed necessary by the department for maintenance contractor eligibility.
History.—s. 90, ch. 29965, 1955; s. 1, ch. 61-432; s. 1, ch. 61-443; s. 1, ch. 61-222; s. 1, ch. 65-4; s. 5, ch. 67-461; s. 1, ch. 69-315; s. 1, ch. 69-392; ss. 23, 35, ch. 69-106; s. 1, ch. 70-325; s. 114, ch. 71-377; s. 1, ch. 72-88; s. 1, ch. 75-6; s. 3, ch. 76-85; s. 1, ch. 84-277; s. 139, ch. 84-309; s. 32, ch. 86-243; s. 1, ch. 87-93; s. 5, ch. 87-100; s. 1, ch. 87-104; s. 1, ch. 87-162; s. 6, ch. 88-91; s. 5, ch. 88-93; s. 14, ch. 88-168; s. 1, ch. 89-160; s. 12, ch. 89-301; s. 46, ch. 90-136; s. 120, ch. 92-152; s. 27, ch. 93-164; s. 14, ch. 94-237; s. 963, ch. 95-148; s. 35, ch. 95-196; s. 26, ch. 95-257; s. 36, ch. 96-323; s. 70, ch. 96-410; s. 1, ch. 99-345; s. 18, ch. 99-385; ss. 2, 4, ch. 2001-350; ss. 10, 11, 12, ch. 2002-20; s. 3, ch. 2005-281; ss. 15, 16, ch. 2005-290; s. 3, ch. 2007-66; s. 32, ch. 2007-196; s. 7, ch. 2009-85; s. 9, ch. 2014-223; s. 4, ch. 2017-42; s. 24, ch. 2022-4; s. 11, ch. 2023-70; s. 9, ch. 2023-197.
337.1101 Contracting and procurement authority of the department; settlements; notification required.—
(1) When the department, or any entity or enterprise within the department, determines that it is in the best interest of the public to resolve a protest filed in accordance with s. 120.57(3) of the award of a contract being procured pursuant to s. 337.11 or related to the purchase of personal property or contractual services being procured pursuant to s. 287.057, through a settlement that requires the department to pay a nonselected responsive bidder a total sum of $1 million or more, including any amount paid pursuant to s. 334.049, any amount paid pursuant to s. 337.11(8) which is not included in the department’s work program approved by the Legislature as part of the General Appropriations Act, or any amount paid pursuant to any other law, the department must:
(a) Document in a written memorandum by the secretary the specific reasons that such settlement and payment to a nonselected responsive bidder is in the best interest of the state. The written memorandum must be included and maintained in the department’s permanent files concerning the procurement and must include:
1. A description of the property rights, patent rights, copyrights, trademarks, or the engineering design or other design work that the department will acquire or retain as a result of such settlement; and
2. The specific appropriation in the existing General Appropriations Act which the department intends to use to provide such payment.
(b) Provide prior written notification to the President of the Senate, the Speaker of the House of Representatives, the Senate and House of Representatives minority leaders, the chair and vice chair of the Legislative Budget Commission, and the Attorney General at least 5 business days, or as soon thereafter as practicable, before the department makes the settlement agreement final. Such written notification must include the written memorandum required pursuant to paragraph (a).
(c) Provide, at the time settlement discussions regarding any such payment have begun in earnest, written notification of such discussions to the President of the Senate, the Speaker of the House of Representatives, the Senate and House of Representatives minority leaders, the chair and vice chair of the Legislative Budget Commission, and the Attorney General.
(2) The department may not pledge any current or future action by another branch of state government as a condition of any procurement action. Any settlement that commits the state to spending any amount in excess of current appropriations, to the appropriation of funds in a subsequent fiscal year, or to policy changes inconsistent with current state law must be contingent upon and subject to legislative appropriation or statutory amendment. The department may agree to use its efforts to procure legislative funding or statutory amendments.
History.—s. 6, ch. 2019-43; s. 10, ch. 2023-197.
337.111 Contracting for monuments and memorials to military veterans at rest areas.—The Department of Transportation is authorized to enter into contract with any not-for-profit group or organization that has been operating for not less than 2 years for the installation of monuments and memorials honoring Florida’s military veterans at highway rest areas around the state pursuant to the provisions of this section.
(1) Proposals for contracts must be approved by a committee composed of the Secretary of Transportation or the secretary’s designee, the executive director of the Department of Veterans’ Affairs or the executive director’s designee, and three members of the board of directors of the direct-support organization established under s. 292.055, appointed by the executive director of the Department of Veterans’ Affairs. The terms of the appointed members may not exceed 2 years and shall run concurrently with the members’ terms on the board of directors of the direct-support organization. Appointed members may be reappointed to the committee.
(2) Installations may consist of monuments or other memorials, plaques, markers, or retired military equipment that honor the accomplishments of military veterans and the sacrifices made by them and their families.
(3) The group or organization making the proposal shall be responsible for all costs of the monument and its installation.
(4) The group or organization making the proposal shall provide an annual renewable bond, an irrevocable letter of credit, or another form of security as approved by the department’s comptroller, for the purpose of securing the cost of removal of the monument and any modifications made to the site as part of the placement of the monument should the Department of Transportation determine it necessary to remove or relocate the monument. Such removal or relocation shall be approved by the committee described in subsection (1).
History.—s. 3, ch. 2005-43; s. 4, ch. 2008-84; s. 29, ch. 2012-174.
337.125 Socially and economically disadvantaged business enterprises; notice requirements.—
(1) When contract goals are established, in order to document that a subcontract is with a certified socially and economically disadvantaged business enterprise, the prime contractor must either submit a disadvantaged business enterprise utilization form which has been signed by the socially and economically disadvantaged business enterprise and the prime contractor, or submit the written or oral quotation of the socially and economically disadvantaged business enterprise, and information contained in the quotation must be confirmed as determined by the department by rule.
(2) The department shall provide reasonable advance notice of the date of the preconstruction conference to each socially and economically disadvantaged business enterprise utilized by the prime contractor in meeting the socially and economically disadvantaged business enterprise contract goals.
(3) The department shall provide a socially and economically disadvantaged business enterprise with reasonable advance notice prior to removing such enterprise from any area of specialization of certified socially and economically disadvantaged business enterprises.
(4) The department shall promulgate rules for implementing the directives contained in this section.
History.—s. 2, ch. 87-93; s. 15, ch. 90-227; s. 30, ch. 2012-174.
337.135 Socially and economically disadvantaged business enterprises; punishment for false representation.—
(1) It is unlawful for any individual to fraudulently represent an entity as a socially and economically disadvantaged business enterprise for purposes of qualifying for certification as such an enterprise under a program of the department designed to assist socially and economically disadvantaged business enterprises in the receipt of contracts with the department for the provision of goods or services. Any person who violates this section is guilty of a felony of the second degree, punishable as provided in s. 775.082, s. 775.083, or s. 775.084.
(2) An individual found in violation of subsection (1) shall not create a new corporate structure for the purpose of circumventing this section.
History.—s. 3, ch. 87-93.
337.139 Efforts to encourage awarding contracts to disadvantaged business enterprises.—In implementing chapter 90-136, Laws of Florida, the Department of Transportation shall institute procedures to encourage the awarding of contracts for professional services and construction to disadvantaged business enterprises. For the purposes of this section, the term “disadvantaged business enterprise” means a small business concern certified by the Department of Transportation to be owned and controlled by socially and economically disadvantaged individuals as defined by the Safe, Accountable, Flexible, Efficient Transportation Equity Act: A Legacy for Users (SAFETEA-LU). The Department of Transportation shall develop and implement activities to encourage the participation of disadvantaged business enterprises in the contracting process. Such efforts may include:
(1) Presolicitation or prebid meetings for the purpose of informing disadvantaged business enterprises of contracting opportunities.
(2) Written notice to disadvantaged business enterprises of contract opportunities for commodities or contractual and construction services which the disadvantaged business provides.
(3) Provision of adequate information to disadvantaged business enterprises about the plans, specifications, and requirements of contracts or the availability of jobs.
(4) Breaking large contracts into several single-purpose contracts of a size which may be obtained by certified disadvantaged business enterprises.
History.—s. 45, ch. 90-136; s. 84, ch. 99-385; s. 32, ch. 2012-174.
337.14 Application for qualification; certificate of qualification; restrictions; request for hearing.—
(1) Any contractor desiring to bid for the performance of any construction contract in excess of $250,000 which the department proposes to let must first be certified by the department as qualified pursuant to this section and rules of the department. The rules of the department must address the qualification of contractors to bid on construction contracts in excess of $250,000 and must include requirements with respect to the equipment, past record, experience, financial resources, and organizational personnel of the applying contractor which are necessary to perform the specific class of work for which the contractor seeks certification. Any contractor who desires to bid on contracts in excess of $50 million and who is not qualified and in good standing with the department as of January 1, 2019, must first be certified by the department as qualified and must have satisfactorily completed two projects, each in excess of $15 million, for the department or for any other state department of transportation. The department may limit the dollar amount of any contract upon which a contractor is qualified to bid or the aggregate total dollar volume of contracts such contractor is allowed to have under contract at any one time. Each applying contractor seeking qualification to bid on construction contracts in excess of $250,000 shall furnish the department a statement under oath, on such forms as the department may prescribe, setting forth detailed information as required on the application. Each application for certification must be accompanied by audited, certified financial statements prepared in accordance with generally accepted accounting principles and auditing standards by a certified public accountant licensed in this state or another state. The audited, certified financial statements must be for the applying contractor and must have been prepared within the immediately preceding 12 months. The department may not consider any financial information of the parent entity of the applying contractor, if any. The department may not certify as qualified any applying contractor who fails to submit the audited, certified financial statements required by this subsection. If the application or the annual financial statement shows the financial condition of the applying contractor more than 4 months before the date on which the application is received by the department, the applicant must also submit interim audited, certified financial statements prepared in accordance with generally accepted accounting principles and auditing standards by a certified public accountant licensed in this state or another state. The interim financial statements must cover the period from the end date of the annual statement and must show the financial condition of the applying contractor no more than 4 months before the date that the interim financial statements are received by the department. However, upon the request of the applying contractor, an application and accompanying annual or interim financial statement received by the department within 15 days after either 4-month period under this subsection shall be considered timely. An applying contractor desiring to bid exclusively for the performance of construction contracts with proposed budget estimates of less than $2 million may submit reviewed annual or reviewed interim financial statements prepared by a certified public accountant. The information required by this subsection is confidential and exempt from s. 119.07(1). The department shall act upon the application for qualification within 30 days after the department determines that the application is complete. The department may waive the requirements of this subsection for projects having a contract price of $500,000 or less if the department determines that the project is of a noncritical nature and the waiver will not endanger public health, safety, or property.
(2) Certification shall be necessary in order to bid on a road, bridge, or public transportation construction contract of more than $250,000. However, the successful bidder on any construction contract must furnish a contract bond prior to the award of the contract. The department may waive the requirement for all or a portion of a contract bond for contracts of $150,000 or less under s. 337.18(1).
(3) Upon the receipt of an application for certification, the department shall examine it, verify its statements when necessary, and determine whether the applicant is competent, is responsible, and possesses the necessary financial resources to perform the desired work.
(4) If the applicant is found to possess the prescribed qualifications, the department shall issue to him or her a certificate of qualification that, unless thereafter revoked by the department for good cause, will be valid for a period of 18 months after the date of the applicant’s financial statement or such shorter period as the department prescribes. Submission of an application does not affect expiration of the certificate of qualification. An applicant may submit a written request with a timely submitted application to keep an existing certificate of qualification in place until the expiration date. If the request is approved by the department, the current maximum capacity rating of the applicant must remain in place until expiration of the current certificate of qualification. If the department finds that an application is incomplete or contains inadequate information or information that cannot be verified, the department may request in writing that the applicant provide the necessary information to complete the application or provide the source from which any information in the application may be verified. If the applicant fails to comply with the initial written request within a reasonable period of time as specified therein, the department shall request the information a second time. If the applicant fails to comply with the second request within a reasonable period of time as specified therein, the application shall be denied.
(5) The certificate of qualification shall contain a statement fixing the actual amount of work, in terms of estimated cost, which the applicant will be permitted to have on contract with the department and not completed at any one time, and the certificate may contain a statement by the department limiting such bidder to the submission of bids upon a certain class of work. Subject to such restrictions, the certificate of qualification shall authorize the holder to bid on all work on which bids are taken by the department during the period of time specified in the certificate.
(6) Any applicant for a certificate of qualification who is aggrieved by the action of the department may, within 10 days after receiving notification of such action, request a hearing pursuant to chapter 120.
(7) A “contractor” as defined in s. 337.165(1)(d) or his or her “affiliate” as defined in s. 337.165(1)(a) qualified with the department under this section may not also qualify under s. 287.055 or s. 337.105 to provide testing services, construction, engineering, and inspection services to the department. This limitation does not apply to any design-build prequalification under s. 337.11(7) and does not apply when the department otherwise determines by written order entered at least 30 days before advertisement that the limitation is not in the best interests of the public with respect to a particular contract for testing services, construction, engineering, and inspection services. This subsection does not authorize a contractor to provide testing services, or provide construction, engineering, and inspection services, to the department in connection with a construction contract under which the contractor is performing any work. Notwithstanding any other provision of law to the contrary, for a project that is wholly or partially funded by the department and administered by a local governmental entity, except for a seaport listed in s. 311.09 or an airport as defined in s. 332.004, the entity performing design and construction engineering and inspection services may not be the same entity.
(8) This section does not apply to maintenance contracts.
(9)(a) Notwithstanding any other law to the contrary, for contracts in excess of $250,000, an authority created pursuant to chapter 348 or chapter 349 may require that persons interested in performing work under contract first be certified or qualified to do the work. Any contractor may be considered ineligible to bid by the governmental entity or authority if the contractor is behind an approved progress schedule for the governmental entity or authority by 10 percent or more at the time of advertisement of the work. Any contractor prequalified and considered eligible by the department to bid to perform the type of work described under the contract shall be presumed to be qualified to perform the work so described. The governmental entity or authority may provide an appeal process to overcome that presumption with de novo review based on the record below to the circuit court.
(b) With respect to contractors not prequalified with the department, the authority shall publish prequalification criteria and procedures prior to advertisement or notice of solicitation. Such publications shall include notice of a public hearing for comment on such criteria and procedures prior to adoption. The procedures shall provide for an appeal process within the authority for objections to the prequalification process with de novo review based on the record below to the circuit court within 30 days.
(c) An authority may establish criteria and procedures under which contractor selection may occur on a basis other than the lowest responsible bidder. Prior to adoption, the authority shall publish for comment the proposed criteria and procedures. Review of the adopted criteria and procedures shall be to the circuit court, within 30 days after adoption, with de novo review based on the record below.
History.—s. 93, ch. 29965, 1955; s. 14, ch. 57-318; s. 1, ch. 61-501; s. 1, ch. 69-314; ss. 23, 35, ch. 69-106; s. 1, ch. 76-85; s. 1, ch. 78-316; s. 10, ch. 80-374; s. 1, ch. 83-18; s. 146, ch. 84-309; s. 33, ch. 86-243; s. 6, ch. 87-100; s. 2, ch. 89-21; s. 495, ch. 95-148; s. 37, ch. 95-257; s. 37, ch. 96-323; s. 161, ch. 96-406; s. 43, ch. 97-96; s. 80, ch. 2002-20; s. 43, ch. 2003-286; s. 4, ch. 2007-66; s. 33, ch. 2007-196; s. 21, ch. 2010-225; s. 33, ch. 2012-174; s. 10, ch. 2014-223; s. 1, ch. 2019-86; s. 4, ch. 2019-153; s. 10, ch. 2021-188; s. 14, ch. 2022-204; s. 11, ch. 2023-197.
337.141 Payment of construction or maintenance contracts.—
(1) As used in this section, the terms “dispute” or “pending claim” refer to a dispute or pending claim between the prime contractor and the department.
(2) Each contract for construction or maintenance entered into pursuant to this chapter shall provide for final payment within 75 days of final field acceptance, provided all documents which are required by the contract from the contractor, with the exception of the acceptance letter and a consent by the contractor’s surety for release of payment of the retained percentage and final estimate to the contractor, are received within 30 days of final field acceptance. If the contractor fails to provide the documents within 30 days after final field acceptance, payment shall be made within 45 days of receipt by the department of such documents. The department shall notify the contractor within 20 days of receipt of the documents which are required for payment if such documents are incomplete and shall specifically list for the contractor which documents have not been submitted. Should the department fail to notify the contractor within 20 days, regardless of completeness of the documents, the time required for payment shall begin. The period of time from the offer of final payment to the receipt by the department of the acceptance letter and surety’s consent shall not count as part of the 75-day or 45-day time periods. Final payment shall not be so made as to any amount which is in dispute or the subject of a pending claim, but shall be so made as to that portion of a contract or those amounts which are not in dispute or the subject of a pending claim. However, such partial payment shall not constitute any bar, admission, or estoppel or have any other effect as to those payments that are in dispute or the subject of a pending claim. No payment may be made to a construction or maintenance contractor until the department has on file proof, in the form of a notarized affidavit from the contractor, that all motor vehicles that he or she operates in this state are registered in compliance with chapter 320.
(3) For each day after 75 days, or 30 days after settlement of a claim, the department shall pay to the contractor interest at the rate set forth in s. 55.03.
(4) If a contractor fails to submit all documents required for final payment within 2 years after final acceptance of the work or within 1 year after the offer by the department of final payment, whichever occurs later, any amount owed as final payment shall be considered to be forfeited. The forfeiture will not apply to documents that are the subject of existing claims or pending legal proceedings. Written notice shall be given by the department at least 60 days prior to forfeiture.
History.—ss. 1, 2, ch. 70-168; s. 1, ch. 77-79; s. 147, ch. 84-309; s. 2, ch. 87-104; s. 1, ch. 88-281; s. 11, ch. 94-239; s. 964, ch. 95-148.
337.145 Offsetting payments.—
(1) After settlement, arbitration, or final adjudication of any claim of the department for work done pursuant to a construction contract with any party, the department may offset such amount from payments due for work done on any construction contract, excluding amounts owed to subcontractors, suppliers, and laborers, which it has with the party owing such amount if, upon demand, payment of the amount is not made within 60 days to the department.
(2) Offsetting any amounts pursuant to subsection (1) shall not be considered a breach of contract by the department.
History.—s. 7, ch. 87-100; s. 39, ch. 91-221.
337.16 Disqualification of delinquent contractors from bidding; determination of contractor nonresponsibility; denial, suspension, and revocation of certificates of qualification; grounds; hearing.—
(1) A contractor shall not be qualified to bid when an investigation by the department discloses that such contractor is delinquent on a previously awarded contract, and in such case the contractor’s certificate of qualification shall be suspended or revoked. Any contractor whose certificate of qualification is suspended or revoked for delinquency shall also be disapproved as a subcontractor during the period of suspension or revocation, except when a prime contractor’s bid has used prices of a subcontractor who becomes disqualified after the bid and before the request for authorization to sublet is presented.
(a) A contractor is delinquent when the allowed contract time has expired and the contract work is not complete.
(b) The department shall inform the contractor in writing of its intent to deny, suspend, or revoke his or her certificate of qualification to bid on work let by the department for delinquency and inform the contractor of his or her right to a hearing, the procedure which must be followed, and the applicable time limits. If a hearing is requested within 10 days after the receipt of the notice of intent, the hearing shall be held within 30 days after receipt by the administrative law judge of the request for the hearing. The recommended order shall be issued within 15 days after the hearing. The contractor’s application for a certificate of qualification shall be denied or the contractor’s current certificate of qualification shall be suspended for the number of days that it is administratively determined that the contractor was delinquent even if the delinquency is cured during the pendency of the hearing proceedings.
(c) In addition to the period of suspension required in paragraph (b), the department shall deny or suspend the certificate of qualification of such contractor in accordance with the following schedule: If a contractor has been suspended twice within an 18-month period, the period of suspension shall be 3 months; if such contractor has been suspended twice within a 24-month period, the period of suspension shall be 2 months; and, if such contractor has been suspended 3 times within a 30-month period, the period of suspension shall be 4 months. The department shall inform the contractor in writing of its intent to deny or suspend his or her certificate of qualification to bid on work let by the department and inform the contractor of his or her right to a hearing, the procedure which must be followed, and the applicable time limits. If a hearing is requested within 10 days after the receipt of the notice of intent, the hearing shall be held within 30 days after receipt of the request for the hearing. Upon a determination that the contractor’s certificate of qualification had been suspended for delinquency, it shall deny or suspend the certificate of the contractor as provided in this paragraph.
(d) Such suspension or revocation shall not affect the contractor’s obligations under any preexisting contract.
(2) For reasons other than delinquency in progress, the department, for good cause, may determine any contractor not having a certificate of qualification nonresponsible for a specified period of time or may deny, suspend, or revoke any certificate of qualification. Good cause includes, but is not limited to, circumstances in which a contractor or the contractor’s official representative:
(a) Makes or submits to the department false, deceptive, or fraudulent statements or materials in any bid proposal to the department, any application for a certificate of qualification, any certification of payment pursuant to s. 337.11(11), or any administrative or judicial proceeding;
(b) Becomes insolvent or is the subject of a bankruptcy petition;
(c) Fails to comply with contract requirements, in terms of payment or performance record, or to timely furnish contract documents as required by the contract or by any state or federal statute or regulation;
(d) Wrongfully employs or otherwise provides compensation to any employee or officer of the department, or willfully offers an employee or officer of the department any pecuniary or other benefit with the intent to influence the employee or officer’s official action or judgment;
(e) Is an affiliate of a contractor who has been determined nonresponsible or whose certificate of qualification has been suspended or revoked and the affiliate is dependent upon such contractor for personnel, equipment, bonding capacity, or finances; or
(f) Fails to register, pursuant to chapter 320, motor vehicles that he or she operates in this state.
History.—s. 95, ch. 29965, 1955; ss. 23, 35, ch. 69-106; s. 56, ch. 78-95; s. 150, ch. 84-309; s. 27, ch. 85-180; s. 5, ch. 87-93; s. 8, ch. 87-100; s. 3, ch. 87-104; s. 47, ch. 90-136; s. 15, ch. 94-237; s. 965, ch. 95-148; s. 71, ch. 96-410; s. 19, ch. 99-385; s. 66, ch. 2010-5.
337.162 Professional services.—Professional services provided to the department that fall below acceptable professional standards may result in transportation project delays, overruns, and reduced facility life. To minimize these effects and ensure that quality services are received, the Legislature hereby declares that licensed professionals shall be held accountable for the quality of the services they provide to the department.
(1) If the department has knowledge or reason to believe that any person has violated the provisions of state professional licensing laws or rules, it shall submit a complaint about the violations to the Department of Business and Professional Regulation. The complaint submitted to the Department of Business and Professional Regulation and maintained by the department is confidential and exempt from s. 119.07(1).
(2) Any person who is employed by the department and who is licensed by the Department of Business and Professional Regulation and who, through the course of his or her employment, has knowledge or reason to believe that any person has violated the provisions of state professional licensing laws or rules shall submit a complaint about the violations to the Department of Business and Professional Regulation. Failure to submit a complaint about the violations may be grounds for disciplinary action pursuant to chapter 455 and the state licensing law applicable to that licensee. However, licensees under part II of chapter 475 are exempt from the provisions of s. 455.227(1)(i). The complaint submitted to the Department of Business and Professional Regulation and maintained by the department is confidential and exempt from s. 119.07(1).
(3) Any complaints submitted to the Department of Business and Professional Regulation pursuant to subsections (1) and (2) are confidential and exempt from s. 119.07(1) pursuant to chapter 455 and applicable state law.
(4) In order to inform licensed professionals of the requirements of this section, the department shall include the requirements of this section in contracts with persons licensed by the Department of Business and Professional Regulation.
History.—s. 42, ch. 90-136; s. 35, ch. 94-218; s. 966, ch. 95-148; s. 1, ch. 95-255; s. 162, ch. 96-406; s. 18, ch. 98-166; s. 20, ch. 99-385; s. 8, ch. 2000-160.
337.164 Legislative intent with respect to integrity of public contracting process.—Recognizing that the preservation of the integrity of the public contracting process of the department is vital to the development of a balanced and efficient transportation system and is a matter of interest to all the people of the state, the Legislature determines and declares that:
(1) The procedures of the department for bidding and qualification of bidders on department contracts exist to secure the public benefits of free and open competition and to secure the quality of public works.
(2) The opportunity to bid on department contracts or to supply goods or services to the department is a privilege, not a right.
(3) The privilege of transacting business with the department should be denied to persons or firms involved in contract crime in order to preserve the integrity of the public contracting process.
(4) Persons or firms involved in contract crime should be denied both the privilege of transacting business with the department and the opportunity of obtaining economic benefit through the transaction of business by their affiliates with the department.
To this end, it is the intent of the Legislature to provide sufficiently broad authority to the department to ensure the integrity of its public contracting process.
History.—s. 1, ch. 83-4; s. 151, ch. 84-309.
337.165 Contract crime; denial or revocation of a certificate of qualification.—
(1) The following words and phrases, when used in this section, have the following meanings:
(a) The term “affiliate” means a predecessor or successor of a contractor under the same, or substantially the same, control or a group of business entities which are connected or associated so that one entity controls or has the power to control each of the other business entities. The term “affiliate” includes the officers, directors, executives, shareholders active in management, employees, and agents of the affiliate. The ownership by one business entity of a controlling interest in another business entity or a pooling of equipment or income among business entities shall be prima facie evidence that one business entity is an affiliate of another.
(b) The term “certificate” means the certificate of qualification required and granted pursuant to s. 337.14 or other form of authorization issued pursuant to s. 337.105.
(c) The term “contract crime” means any violation of state or federal antitrust laws with respect to a public contract or any violation of any state or federal law involving fraud, bribery, collusion, conspiracy, or material misrepresentation with respect to a public contract.
(d) The term “contractor” means any person who bids or applies to bid on work let by the department or any counterpart agency of any other state or of the Federal Government or who provides professional services to the department or other such agency. The term “contractor” includes the officers, directors, executives, shareholders active in management, employees, and agents of the contractor.
(e) The term “convicted” or “conviction” means a finding of guilt or a conviction of a contract crime, with or without an adjudication of guilt, in any federal or state trial court of record as a result of a jury verdict, nonjury trial, or entry of a plea of guilty or nolo contendere.
(f) The term “pooling” means a combination of persons or corporations engaged in the same business, or for the purpose of engaging in a particular business or commercial or speculative venture, in which all contribute to a common fund or place their holdings of a given stock or other security in the hands and control of a managing member or committee.
(2)(a) No contractor or his or her affiliate shall be qualified to bid on work let by the department when it is determined that he or she has, subsequent to January 1, 1978, been convicted of a contract crime within the jurisdiction of any state or federal court.
(b)1. Any provision of chapter 120 to the contrary notwithstanding, when the department receives notice that a contractor has been convicted of a contract crime, the department shall inform the contractor or the contractor’s affiliate in writing of its intent to deny or revoke the certificate of the contractor or affiliate to bid on work let by the department and of the contractor’s right to a hearing, the procedure which must be followed, and the applicable time limits. If a hearing is requested within 10 days of receipt of the notice of intent, the department shall notify the contractor or affiliate of the time, date, and place of the hearing, which hearing shall be held within 30 days of receipt of the request for the hearing. If the department determines that the contractor has been convicted of a contract crime, it shall deny or revoke the certificate of the contractor or affiliate for a period of 36 months.
2. Any person who is notified by the department of its intent to deny or revoke his or her certificate to bid on work let by the department because of his or her status as an affiliate of a contractor convicted of a contract crime may, at the hearing requested under subparagraph 1., offer proof that he or she is not an affiliate as defined by paragraph (1)(a). The submission of an affidavit alone shall not constitute competent substantial evidence that the person is not an affiliate. If the department finds that such person is not an affiliate, the person’s certificate may not be denied or revoked.
(c) A contractor or affiliate whose certificate has been denied or revoked because of a conviction of a contract crime and who is subsequently convicted of a contract crime committed within 10 years of such denial or revocation may not be considered for eligibility pursuant to paragraph (d) until 24 months after the date of the denial or revocation based upon such subsequent conviction.
(d) A contractor or affiliate whose certificate has been denied or revoked may, at any time after denial or revocation, petition for and be granted a hearing to determine his or her eligibility for reapplication or reinstatement upon such terms and conditions as may be prescribed upon finding that reapplication or reinstatement is in the public interest. The petition shall be filed with the department. Any hearing conducted by the department shall be conducted within 30 days after receipt of the petition, unless otherwise stipulated by the parties. If the contractor or affiliate requests in his or her petition that the hearing be conducted by the Division of Administrative Hearings of the Department of Management Services, the department shall, within 5 days after receipt of the petition, notify the division of the request. The director of the Division of Administrative Hearings shall, within 5 days after the notice by the department, assign an administrative law judge, who shall conduct the hearing within 30 days thereafter, unless otherwise stipulated by the parties. The department shall be a party in interest in any hearing conducted by the Division of Administrative Hearings. In determining whether reapplication or reinstatement would be in the public interest, the department or division administrative law judge shall give consideration to any relevant mitigating circumstances, which may include, but are not limited to, the following:
1. The degree of culpability;
2. Prompt and voluntary payment of damages to the state as a result of the contractor’s violation of state or federal antitrust laws;
3. Cooperation with any state or federal prosecution or investigation of a contract crime;
4. Disassociation with those involved in a contract crime;
5. Reinstatement in other state or federal jurisdictions; and
6. The needs of the department in completing its programs in a timely, cost-effective manner.
The department or division administrative law judge shall also consider the failure of the contractor or affiliate to comply with the notification provisions of subsection (5). Any hearing requested under this paragraph shall be conducted and concluded without undue delay. The administrative law judge shall, within 30 days after the hearing, complete and submit a final order to the department, which order may not be altered or amended by the department. If eligibility for reapplication or reinstatement is denied, the contractor or affiliate may not petition for a subsequent hearing for a period of 9 months following the date of the order of denial or revocation. However, a hearing prior to the expiration of such period may be authorized by the department if, in its discretion, it determines that a hearing is in the public interest.
(3) A contractor or affiliate whose certificate is denied or revoked pursuant to this section may not act as a prime contractor, a material supplier, a subcontractor, or a consultant on any department contract or project during the period of such denial or revocation.
(4) The denial or revocation of a contractor’s or affiliate’s certificate shall not affect the contractor’s or affiliate’s obligations under any preexisting contract.
(5) A contractor or the contractor’s affiliate who is currently qualified or seeking to be qualified by the department shall notify the department within 30 days after conviction of a contract crime applicable to him or her or to any of his or her affiliates, or to any of the contractor’s or the contractor’s affiliate’s officers, directors, executives, shareholders active in management, employees, or agents.
(6) Whenever the department has reason to believe that a contractor or the contractor’s affiliate who is currently qualified or seeking to be qualified by the department has been convicted of a contract crime, or may be affiliated with a person so convicted, the department may issue a written demand upon the contractor or affiliate, concerning any such conviction or affiliation, to appear and be examined under oath, to answer written interrogatories under oath, and to produce documents or other tangible evidence for inspection and copying.
History.—s. 2, ch. 83-4; s. 152, ch. 84-309; s. 120, ch. 92-279; s. 55, ch. 92-326; s. 496, ch. 95-148; s. 72, ch. 96-410.
337.166 Moneys recovered for violations of antitrust laws.—In accordance with the provisions of s. 16.53, 30 percent of all moneys recovered from a contractor or its affiliate on behalf of the state by reason of any decree or settlement in any state or federal antitrust claim prosecuted by the Attorney General shall be deposited in the Legal Affairs Revolving Trust Fund. The remainder of the moneys recovered shall be deposited in the State Transportation Trust Fund instead of the General Revenue Fund as generally provided under s. 16.53.
History.—s. 3, ch. 83-4; s. 15, ch. 94-316.
337.167 Administrative procedures; stays and injunctions.—
(1) A certificate to bid on a department contract, or to supply services to the department, is intended to assist the department in determining in advance the performance capabilities of entities seeking to supply goods and services to the department and is not a “license” as defined in s. 120.52. The denial or revocation of a certificate is not subject to the provisions of s. 120.60 or s. 120.68(3). The provisions of ss. 120.569 and 120.57 are applicable to the denial or revocation of such certificate.
(2) For the purpose of promulgating emergency rules, the continuation of the bidding, contracting, or supplying privileges of a convicted contractor or its affiliate represents an immediate danger to the public health, safety, and welfare.
(3) The denial or revocation of a certificate for reasons of contract crime may not be stayed by the department or by the Division of Administrative Hearings during the pendency of any judicial review proceedings concerning a final order of denial or revocation.
(4) A court may grant a stay or injunction in an action relating to the denial or revocation of a certificate only upon the posting of a bond by the petitioner seeking a stay or injunction, and provided the court granting the stay or injunction finds that:
(a) The petitioner has a substantial likelihood of success on the merits;
(b) The threatened harm or injury to the petitioner clearly outweighs any possible injury to the state occasioned by granting the stay or injunction; and
(c) It is in the public interest to grant the stay or injunction.
History.—s. 4, ch. 83-4; s. 40, ch. 91-221; s. 73, ch. 96-410.
337.168 Confidentiality of official estimates and bid analysis and monitoring system.—
(1) A document or electronic file revealing the official cost estimate of the department of a project is confidential and exempt from the provisions of s. 119.07(1) until the contract for the project has been executed or until the project is no longer under active consideration.
(2) The bid analysis and monitoring system of the department is confidential and exempt from the provisions of s. 119.07(1). This exemption applies to all system documentation, input, computer processes and programs, electronic data files, and output, but does not apply to the actual source documents, unless otherwise exempted under other provisions of law.
History.—s. 5, ch. 83-4; s. 3, ch. 89-21; s. 108, ch. 90-360; s. 163, ch. 96-406; s. 11, ch. 2014-223; s. 12, ch. 2023-197.
337.169 Effect of ch. 83-4 on existing remedies.—The provisions of chapter 83-4, Laws of Florida, are not in derogation of existing remedies available to the department, and such remedies remain in full force and effect.
History.—s. 7, ch. 83-4.
337.17 Bid guaranty.—The department shall only require guaranty with each bid for a construction contract in excess of $150,000 in an amount to be specified by the department which shall not exceed 10 percent of the preliminary estimate of the cost of the work. The guaranty may, in the discretion of the bidder, be in the form of a cashier’s check, bank money order, bank draft of any national or state bank, certified check, or surety bond, payable to the department. The surety on any bid bond shall be a company recognized to execute bid bonds for contracts of the Federal Government.
History.—s. 96, ch. 29965, 1955; s. 16, ch. 57-318; ss. 23, 35, ch. 69-106; s. 1, ch. 77-174; s. 157, ch. 84-309; s. 16, ch. 91-162; s. 127, ch. 92-152.
337.175 Retainage.—The department may provide in its construction contracts for retaining a portion of the amount due a contractor for work that the contractor has completed, until completion and final acceptance of the project by the department. If the department allows, contractors may substitute securities as provided by s. 255.052, or substitute certificates of deposit or irrevocable letters of credit approved by the department comptroller in lieu of retainage.
History.—s. 9, ch. 87-100; s. 48, ch. 90-136; s. 122, ch. 92-152; s. 497, ch. 95-148; s. 13, ch. 2000-266.
337.18 Surety bonds for construction or maintenance contracts; requirement with respect to contract award; bond requirements; defaults; damage assessments.—
(1)(a) A surety bond shall be required of the successful bidder in an amount equal to the awarded contract price. However, the department may choose, in its discretion and applicable only to multiyear maintenance contracts, to allow for incremental annual contract bonds that cumulatively total the full, awarded, multiyear contract price.
1. The department may waive the requirement for all or a portion of a surety bond if:
a. The contract price is $250,000 or less and the department determines that the project is of a noncritical nature and that nonperformance will not endanger public health, safety, or property;
b. The prime contractor is a qualified nonprofit agency for the blind or for the other severely handicapped under s. 413.036(2); or
c. The prime contractor is using a subcontractor that is a qualified nonprofit agency for the blind or for the other severely handicapped under s. 413.036(2). However, the department may not waive more than the amount of the subcontract.
2. If the Secretary of Transportation or the secretary’s designee determines that it is in the best interests of the department to reduce the bonding requirement for a project and that to do so will not endanger public health, safety, or property, the department may waive the requirement of a surety bond in an amount equal to the awarded contract price for a project having a contract price of $250 million or more and, in its place, may set a surety bond amount that is a portion of the total contract price and provide an alternate means of security for the balance of the contract amount that is not covered by the surety bond or provide for incremental surety bonding and provide an alternate means of security for the balance of the contract amount that is not covered by the surety bond. Such alternative means of security may include letters of credit, United States bonds and notes, parent company guarantees, and cash collateral. The department may require alternate means of security if a surety bond is waived. The surety on such bond shall be a surety company authorized to do business in the state. All bonds shall be payable to the department and conditioned for the prompt, faithful, and efficient performance of the contract according to plans and specifications and within the time period specified, and for the prompt payment of all persons defined in s. 713.01 furnishing labor, material, equipment, and supplies for work provided in the contract; however, whenever an improvement, demolition, or removal contract price is $25,000 or less, the security may, in the discretion of the bidder, be in the form of a cashier’s check, bank money order of any state or national bank, certified check, or postal money order. The department shall adopt rules to implement this subsection. Such rules shall include provisions under which the department shall refuse to accept bonds on contracts when a surety wrongfully fails or refuses to settle or provide a defense for claims or actions arising under a contract for which the surety previously furnished a bond.
(b) Before beginning any work under the contract, the contractor shall maintain a copy of the payment and performance bond required under this section at its principal place of business and at the job-site office, if one is established, and the contractor shall provide a copy of the payment and performance bond within 5 days after receiving a written request for the bond. A copy of the payment and performance bond required under this section may also be obtained directly from the department by making a request pursuant to chapter 119. A claimant has a right of action against the contractor and surety for the amount due him or her, including unpaid finance charges due under the claimant’s contract. The action may not involve the department in any expense.
(c) A claimant, except a laborer, who is not in privity with the contractor shall, before commencing or not later than 90 days after commencing to furnish labor, materials, or supplies for the prosecution of the work, furnish the contractor with a notice that he or she intends to look to the bond for protection. A claimant who is not in privity with the contractor and who has not received payment for his or her labor, materials, or supplies shall deliver to the contractor and to the surety written notice of the performance of the labor or delivery of the materials or supplies and of the nonpayment. The notice of nonpayment may be served at any time during the progress of the work or thereafter but not before 45 days after the first furnishing of labor, services, or materials, and not later than 90 days after the final furnishing of the labor, services, or materials by the claimant or, with respect to rental equipment, not later than 90 days after the date that the rental equipment was last on the site of the improvement and available for use. An action by a claimant, except a laborer, who is not in privity with the contractor for the labor, materials, or supplies may not be instituted against the contractor or the surety unless both notices have been given. Written notices required or permitted under this section must be served in accordance with s. 713.18.
(d) An action must be instituted by a claimant, whether in privity with the contractor or not, against the contractor or the surety on the payment bond or the payment provisions of a combined payment and performance bond within 365 days after the final acceptance of the contract work by the department. A claimant may not waive in advance his or her right to bring an action under the bond against the surety. In any action brought to enforce a claim against a payment bond under this section, the prevailing party is entitled to recover a reasonable fee for the services of his or her attorney for trial and appeal or for arbitration, in an amount to be determined by the court, which fee must be taxed as part of the prevailing party’s costs, as allowed in equitable actions.
(e) When a contractor has furnished a payment bond pursuant to this section, he or she may, when the department makes any payment to the contractor, serve a written demand on any claimant who is not in privity with the contractor for a written statement under oath of his or her account showing the nature of the labor or services performed to date, if any; the materials furnished; the materials to be furnished, if known; the amount paid on account to date; the amount due; and the amount to become due, if known, as of the date of the statement by the claimant. Any such demand to a claimant who is not in privity with the contractor must be served on the claimant at the address and to the attention of any person who is designated to receive the demand in the notice to the contractor served by the claimant. The failure or refusal to furnish the statement does not deprive the claimant of his or her rights under the bond if the demand is not served at the address of the claimant or directed to the attention of the person designated to receive the demand in the notice to contractor. The failure to furnish the statement within 60 days after the demand, or the furnishing of a false or fraudulent statement, deprives the claimant who fails to furnish the statement, or who furnishes the false or fraudulent statement, of his or her rights under the bond. If the contractor serves more than one demand for statement of account on a claimant and none of the information regarding the account has changed since the claimant’s last response to a demand, the failure or refusal to furnish such statement does not deprive the claimant of his or her rights under the bond. The negligent inclusion or omission of any information deprives the claimant of his or her rights under the bond to the extent that the contractor can demonstrate prejudice from such act or omission by the claimant. The failure to furnish a response to a demand for statement of account does not affect the validity of any claim on the bond being enforced in a lawsuit filed before the date the demand for statement of account is received by the claimant.
(f) The bonds provided for in this section are statutory bonds. The provisions of s. 255.05 are not applicable to bonds issued pursuant to this section.
(2) The department shall provide in its contracts for the determination of default on the part of any contractor for cause attributable to such contractor. The department shall have no liability for anticipated profits for unfinished work on a contract which has been determined to be in default. Every contract let by the department for the performance of work shall contain a provision for payment to the department by the contractor of liquidated damages due to failure of the contractor to complete the contract work within the time stipulated in the contract or within such additional time as may have been granted by the department. The contractual provision shall include a reasonable estimate of the damages that would be incurred by the department as a result of such failure. The department shall establish a schedule of daily liquidated damage charges, based on original contract amounts, for construction contracts entered into by the department, which schedule shall be incorporated by reference into the contract. The department shall update the schedule of liquidated damages at least once every 2 years, but no more often than once a year. The schedule shall, at a minimum, be based on the average construction, engineering, and inspection costs experienced by the department on contracts over the 2 preceding fiscal years. The schedule shall also include anticipated costs of project-related delays and inconveniences to the department and traveling public. Anticipated costs may include, but are not limited to, road user costs, a portion of the projected revenues that will be lost due to failure to timely open a project to revenue-producing traffic, costs resulting from retaining detours for an extended time, and other similar costs. Any such liquidated damages paid to the department shall be deposited to the credit of the fund from which payment for the work contracted was authorized.
(3) In addition to the provision for payment to the department by the contractor of liquidated damages due to the failure of the contractor to complete the project within the time stipulated in the contract or within such additional time as may have been granted by the department, the department may also recover from the contractor amounts paid by the department for damages suffered by third parties as a result of the contractor’s failure to complete the project within the time stipulated in the contract or within such additional time as may have been granted by the department, unless the failure to timely complete the project was caused by the department’s act or omission. However, nothing herein shall create a cause of action against the department, or against a contractor by an abutting property owner or business entity, where none has previously existed.
(4)(a) If the department determines and adequately documents that the timely completion of any project will provide a substantial benefit to the public health, safety, or welfare; will limit the disruptive effect of construction on the community; or is cost beneficial on a revenue-producing project, the contract for such project may provide for an incentive payment payable to the contractor for early completion of the project or critical phases of the work and for additional damages to be assessed against the contractor for the completion of the project or critical phases of the work in excess of the time specified. All contracts containing such provisions shall be approved by the head of the department or his or her designee. The amount of such incentive payment or such additional damages shall be established in the contract based on an analysis of the cost savings to the traveling public or revenue projections for a revenue-producing project. Any liquidated damages provided for under subsection (2) and any additional damages provided for under this subsection shall be payable to the department because of the contractor’s failure to complete the contract work within the time stipulated in the contract or within such additional time as may have been granted by the department.
(b) The department shall adopt rules to implement this subsection. Such rules shall include procedures and criteria for the selection of projects on which incentive payments and additional damages may be provided for by contract.
(5) Such bonds shall be subject to the additional obligation that the principal and surety executing the same shall be liable to the state in a civil action instituted by the department or any officer of the state authorized in such cases, for double any amount in money or property the state may lose or be overcharged or otherwise defrauded of, by reason of any wrongful or criminal act, if any, of the contractor, the contractor’s agent, or employees.
(6) Unless otherwise provided in this section, service of any document must be made in accordance with s. 713.18.
History.—s. 97, ch. 29965, 1955; s. 1, ch. 65-40; ss. 23, 35, ch. 69-106; s. 1, ch. 71-40; s. 2, ch. 78-316; s. 1, ch. 82-41; s. 23, ch. 83-218; s. 158, ch. 84-309; s. 29, ch. 85-180; s. 10, ch. 87-100; s. 2, ch. 88-281; s. 49, ch. 90-136; s. 121, ch. 92-152; s. 13, ch. 94-237; s. 967, ch. 95-148; s. 50, ch. 96-323; s. 3, ch. 98-105; s. 21, ch. 99-385; s. 14, ch. 2000-266; s. 44, ch. 2003-286; s. 5, ch. 2007-66; s. 34, ch. 2007-196; s. 8, ch. 2009-85; s. 40, ch. 2016-239; s. 2, ch. 2023-226.
337.185 State Arbitration Board.—
(1) To facilitate the prompt resolution of claims arising out of or in connection with a construction or maintenance contract with the department, the Legislature establishes the State Arbitration Board, referred to in this section as the “board.”
(2) As used in this section, the term:
(a) “Claim” means the aggregate of all outstanding written requests for additional monetary compensation, time, or other adjustments to the contract, the entitlement or impact of which is disputed by the department and could not be resolved by negotiation between the department and the contractor.
(b) “Contractor” means a person or firm having a contract for rendering services to the department relating to the construction or maintenance of a transportation facility.
(c) “Final acceptance” means that the contractor has completely performed the work provided for under the contract, the department or its agent has determined that the contractor has satisfactorily completed the work provided for under the contract, and the department or its agent has submitted written notice of final acceptance to the contractor.
(3) Every claim in an amount of up to $250,000 per contract that could not be resolved by negotiation between the department and the contractor must be arbitrated by the board. An award issued by the board pursuant to this section is final and enforceable by a court of law.
(4) The contractor may submit a claim greater than $250,000 up to $1 million per contract or, upon agreement of the parties, up to $2 million per contract to be arbitrated by the board. An award issued by the board pursuant to this subsection is final if a request for a trial de novo is not filed within the time provided by Rule 1.830, Florida Rules of Civil Procedure. At the trial de novo, the court may not admit evidence that there has been an arbitration proceeding, the nature or amount of the award, or any other matter concerning the conduct of the arbitration proceeding, except that testimony given at an arbitration hearing may be used for any purpose otherwise permitted by the Florida Evidence Code. If a request for trial de novo is not filed within the time provided, the award issued by the board is final and enforceable by a court of law.
(5) An arbitration request may not be made to the board before final acceptance but must be made to the board within 820 days after final acceptance.
(6) The board shall schedule a hearing within 45 days after an arbitration request and, if possible, shall conduct the hearing within 90 days after the request. The board may administer oaths and conduct the proceedings as provided by the rules of the court. The hearing shall be conducted informally. Presentation of testimony and evidence shall be kept to a minimum, and matters shall be presented to the arbitrators primarily through the statements and arguments of counsel. The board shall address the scope of discovery, presentation of testimony, and evidence at a preliminary hearing by considering the size, subject matter, and complexity of the dispute. Any party to the arbitration may petition the board, for good cause shown, to issue subpoenas for the attendance of witnesses and the production of books, records, documents, and other evidence at the arbitration and may petition the board for orders compelling such attendance and production at the arbitration. Subpoenas shall be served and are enforceable in the manner provided by law.
(7) The board must issue an award within 45 days after the conclusion of the arbitration hearing. If all three members of the board do not agree, the award agreed to by the majority shall constitute the award of the board.
(8) The board shall be composed of three members. The first member shall be appointed by the Secretary of Transportation, and the second member shall be elected by those construction or maintenance companies that are under contract with the department. The third member shall be chosen by agreement of the first and second members. If the first or second member has a conflict of interest regarding affiliation with one of the parties to an arbitration hearing, the appointing entity shall appoint an alternate member for that hearing. If the third member has such a conflict of interest, the first and second members shall select an alternate member. Each member shall serve a 4-year term. The board shall elect a chair for each term, who shall be the administrator of the board and custodian of its records.
(9) The presence of all board members is required to conduct a meeting in person or via videoconferencing.
(10) The members of the board shall receive compensation for the performance of their duties from deposits made by the parties based on an estimate of compensation by the board, except that an employee of the department may not receive compensation from the board. All deposits will be held in escrow by the chair in advance of the hearing. Each member eligible for compensation shall be compensated at $200 per hour, up to a maximum of $1,500 per day. A member shall be reimbursed for the actual cost of his or her travel expenses. The board may allocate funds annually for clerical and other administrative services.
(11) To cover the cost of administration and initial compensation of the board, the party requesting arbitration shall pay a filing fee to the board, according to a schedule established by the board, of:
(a) Up to $500 for a claim that is $25,000 or less.
(b) Up to $1,000 for a claim that is more than $25,000 but is $50,000 or less.
(c) Up to $1,500 for a claim that is more than $50,000 but is $100,000 or less.
(d) Up to $2,000 for a claim that is more than $100,000 but is $200,000 or less.
(e) Up to $3,000 for a claim that is more than $200,000 but is $300,000 or less.
(f) Up to $4,000 for a claim that is more than $300,000 but is $400,000 or less.
(g) Up to $5,000 for a claim that is more than $400,000.
The board may apportion the filing fees and the cost of recording and preparing a transcript of the hearing among the parties in its award.
History.—s. 1, ch. 69-351; ss. 23, 35, ch. 69-106; s. 1, ch. 70-186; s. 56, ch. 78-95; s. 3, ch. 80-346; s. 170, ch. 84-309; s. 19, ch. 85-180; s. 11, ch. 87-100; s. 14, ch. 90-502; s. 123, ch. 92-152; s. 49, ch. 93-164; s. 498, ch. 95-148; s. 2, ch. 99-345; s. 22, ch. 99-385; s. 13, ch. 2002-20; s. 9, ch. 2009-85; s. 5, ch. 2019-153; s. 11, ch. 2021-188.
Note.—Former s. 337.32.
337.19 Suits by and against department; limitation of actions; forum.—
(1) Suits at law and in equity may be brought and maintained by and against the department on any contract claim arising from breach of an express provision or an implied covenant of a written agreement or a written directive issued by the department pursuant to the written agreement. In any such suit, the department and the contractor shall have all of the same rights and obligations as a private person under a like contract except that no liability may be based on an oral modification of either the written contract or written directive. Nothing herein shall be construed to waive the sovereign immunity of the state and its political subdivisions from equitable claims and equitable remedies. Notwithstanding anything to the contrary contained in this section, no employee or agent of the department may be held personally liable to an extent greater than that pursuant to s. 768.28 provided that no suit sounding in tort shall be maintained against the department.
(2) Suits by and against the department under this section shall be commenced within 820 days of the final acceptance of the work. This section shall apply to all contracts entered into after June 30, 1993.
(3) Any action or suit brought against the department shall be brought in the county or counties where the cause of action accrued, or in the county of the department’s district headquarters responsible for the work, or in Leon County.
History.—s. 98, ch. 29965, 1955; ss. 1, 2, ch. 69-391; s. 1, ch. 84-206; s. 159, ch. 84-309; s. 28, ch. 93-164; s. 158, ch. 96-320; s. 66, ch. 96-323; s. 3, ch. 99-345.
337.195 Limits on liability.—
(1) In a civil action for the death of or injury to a person, or for damage to property, against the Department of Transportation or its agents, consultants, or contractors for work performed on a highway, road, street, bridge, or other transportation facility when the death, injury, or damage resulted from a motor vehicle crash within a construction zone in which the driver of one of the vehicles was under the influence of alcoholic beverages as set forth in s. 316.193, under the influence of any chemical substance as set forth in s. 877.111, or illegally under the influence of any substance controlled under chapter 893 to the extent that her or his normal faculties were impaired or that she or he operated a vehicle recklessly as defined in s. 316.192, it is presumed that the driver’s operation of the vehicle was the sole proximate cause of her or his own death, injury, or damage. This presumption can be overcome if the gross negligence or intentional misconduct of the Department of Transportation, or of its agents, consultants, or contractors, was a proximate cause of the driver’s death, injury, or damage.
(2) A contractor who constructs, maintains, or repairs a highway, road, street, bridge, or other transportation facility for the Department of Transportation is not liable to a claimant for personal injury, property damage, or death arising from the performance of the construction, maintenance, or repair if, at the time of the personal injury, property damage, or death, the contractor was in compliance with contract documents material to the condition that was the proximate cause of the personal injury, property damage, or death.
(a) The limitation on liability contained in this subsection does not apply when the proximate cause of the personal injury, property damage, or death is a latent condition, defect, error, or omission that was created by the contractor and not a defect, error, or omission in the contract documents; or when the proximate cause of the personal injury, property damage, or death was the contractor’s failure to perform, update, or comply with the maintenance of the traffic safety plan as required by the contract documents.
(b) Nothing in this subsection shall be interpreted or construed as relieving the contractor of any obligation to provide the Department of Transportation with written notice of any apparent error or omission in the contract documents.
(c) Nothing in this subsection shall be interpreted or construed to alter or affect any claim of the Department of Transportation against such contractor.
(d) This subsection does not affect any claim of any entity against such contractor, which claim is associated with such entity’s facilities on or in Department of Transportation roads or other transportation facilities.
(3) In all cases involving personal injury, property damage, or death, a person or entity who contracts to prepare or provide engineering plans for the construction or repair of a highway, road, street, bridge, or other transportation facility for the Department of Transportation shall be presumed to have prepared such engineering plans using the degree of care and skill ordinarily exercised by other engineers in the field under similar conditions and in similar localities and with due regard for acceptable engineering standards and principles if the engineering plans conformed to the Department of Transportation’s design standards material to the condition or defect that was the proximate cause of the personal injury, property damage, or death. This presumption can be overcome only upon a showing of the person’s or entity’s gross negligence in the preparation of the engineering plans and shall not be interpreted or construed to alter or affect any claim of the Department of Transportation against such person or entity. The limitation on liability contained in this subsection shall not apply to any hidden or undiscoverable condition created by the engineer. This subsection does not affect any claim of any entity against such engineer or engineering firm, which claim is associated with such entity’s facilities on or in Department of Transportation roads or other transportation facilities.
(4) In any civil action for death, injury, or damages against the Department of Transportation or its agents, consultants, engineers, or contractors for work performed on a highway, road, street, bridge, or other transportation facility, if the department, its agents, consultants, engineers, or contractors are immune from liability pursuant to this section or are not parties to the litigation, they may not be named on the jury verdict form or be found to be at fault or responsible for the injury, death, or damage that gave rise to the damages.
History.—s. 4, ch. 2005-281; s. 34, ch. 2006-1.
337.221 Claims settlement process.—It is the intent of the Legislature that a process be created to resolve contractual claims between the department and providers of goods and services and that the department pursue the recovery of additional costs resulting from substandard goods and services provided to the department.
(1) To implement this policy, the department shall establish a process to resolve claims for additional monetary compensation, time, or other adjustments to the contract.
(2) The department shall document its final decision on all claims, including reasonable support for its decision.
(3) On all claims resolutions resulting in increases of the contract by more than $500,000, a responsible department director, after reasonable inquiry, shall:
(a) Certify that no known facts or circumstances relating to the resolution of the claim indicate any improper intervention or influence, or attempts at any such intervention or influence, on behalf of the consultant or contractor; or
(b) Report to the secretary of the department that facts or circumstances exist that indicate improper intervention or influence, or attempts at such improper intervention or influence, on behalf of the consultant or contractor.
Any such certification or report shall be verified in accordance with s. 92.525.
(4) The recovery for a claim not resolved through the department’s claim settlement process shall only be pursued through state arbitration board or circuit court proceedings, as provided by law.
(5) The department shall annually file a summary report on claim settlements to the transportation committees of the Legislature by October 1 each year. The report shall provide sufficient information to determine whether further inquiry into the claims settlement process is warranted.
History.—s. 13, ch. 87-100; s. 41, ch. 90-136; s. 124, ch. 92-152; s. 71, ch. 94-237; s. 38, ch. 95-257.
337.242 Acquisition of rail corridors.—
(1) The Department of Transportation shall contact each railroad company operating in this state and express the department’s interest in acquiring rail corridors and shall request notification as specified in 49 C.F.R. s. 1152.22(a)(6).
(2) The department shall maintain a map of the rail system in this state.
(3) The department shall control or prohibit ingress to and egress from or through all rail transportation corridors under the department’s jurisdiction.
(4) The department shall, as part of the rail planning responsibilities under s. 341.302(3), identify and evaluate the potential for transportation uses for both operating rail corridors and corridors in which service has been discontinued. If the corridors evaluated have a transportation use potential, the department may purchase, manage, and maintain the corridor subject to appropriation by the Legislature. The movement of people and goods to and from Florida seaports and airports shall be considered a transportation use. All rail transportation corridors in which service has been discontinued or in which service is scheduled for discontinuance shall be reported by the department to the Department of Environmental Protection as specified in s. 260.0161.
History.—s. 24, ch. 88-168; s. 77, ch. 90-136; s. 85, ch. 91-221; s. 165, ch. 94-356.
337.243 Notification of land use changes in designated transportation corridors.—
(1) If a local government designates a transportation corridor that includes a facility on the State Highway System in its local government comprehensive plan and has adopted a transportation corridor management ordinance, the local governmental entity shall give reasonable notice by certified mail to the department prior to approving any substantial zoning change or subdivision plat changes or granting of a building permit or development permit, as defined in s. 380.031(4), for land use or the erection, alteration, or moving of a building for property within the designated transportation corridor which would substantially impair the viability of the corridor for future transportation uses. This notification requirement shall not apply to any routine maintenance or emergency repairs to existing structures. Upon notification, the department shall determine whether to purchase the property affected or to initiate eminent domain proceedings. The department’s determination shall not affect the granting or denial of the permit by the local government. The local government shall not be liable to the department for failure to make notification to the department pursuant to this section.
(2) Any right-of-way located within a designated transportation corridor may be acquired at any time by the department when the acquisition is determined by the department to be in the public interest to protect the designated transportation corridor from development or when the transportation corridor designation creates an undue hardship on the affected property owner.
History.—s. 17, ch. 90-227; s. 40, ch. 95-143; s. 36, ch. 95-257.
337.25 Acquisition, lease, and disposal of real and personal property.—
(1)(a) The department may purchase, lease, exchange, or otherwise acquire any land, property interests, buildings, or other improvements, including personal property within such buildings or on such lands, necessary to secure or use transportation rights-of-way for existing, proposed, or anticipated transportation facilities on the State Highway System, on the State Park Road System, in a rail corridor, or in a transportation corridor designated by the department. Such property shall be held in the name of the state.
(b) The department may accept donations of any land, buildings, or other improvements, including personal property within such buildings or on such lands with or without such conditions, reservations, or reverter provisions as are acceptable to the department. Such donations may be used as transportation rights-of-way or to secure or use transportation rights-of-way for existing, proposed, or anticipated transportation facilities on the State Highway System, on the State Park Road System, or in a transportation corridor designated by the department.
(c) If lands, buildings, or other improvements are needed for transportation purposes, but are held by a federal, state, or local governmental entity and used for public purposes other than transportation, the department may compensate the entity for such properties by providing functionally equivalent replacement facilities. The provision of replacement facilities under this subsection may only be undertaken with the agreement of the governmental entity affected.
(d) The department may contract pursuant to s. 287.055 for auction services used in the conveyance of real or personal property or the conveyance of leasehold interests under subsections (4) and (5). The contract may allow for the contractor to retain a portion of the proceeds as compensation for the contractor’s services.
(2) A complete inventory shall be made of all real or personal property immediately upon possession or acquisition. Such inventory must include a statement of the location or site of each piece of realty, structure, or severable item. Copies of each inventory shall be filed in the district office in which the property is located. Such inventory shall be carried forward to show the final disposition of each item of property, both real and personal.
(3) The inventory of real property that was acquired by the state after December 31, 1988, that has been owned by the state for 10 or more years, and that is not within a transportation corridor or within the right-of-way of a transportation facility shall be evaluated to determine the necessity for retaining the property. If the property is not needed for the construction, operation, and maintenance of a transportation facility or is not located within a transportation corridor, the department may dispose of the property pursuant to subsection (4).
(4) The department may convey, in the name of the state, any land, building, or other property, real or personal, which was acquired under subsection (1) and which the department has determined is not needed for the construction, operation, and maintenance of a transportation facility. When such a determination has been made, property may be disposed of through negotiations, sealed competitive bids, auctions, or any other means the department deems to be in its best interest, with due advertisement for property valued by the department at greater than $10,000. A sale may not occur at a price less than the department’s current estimate of value, except as provided in paragraphs (a)-(d). The department may afford a right of first refusal to the local government or other political subdivision in the jurisdiction in which the parcel is situated, except in a conveyance transacted under paragraph (a), paragraph (c), or paragraph (e). Notwithstanding any provision of this section to the contrary, before any conveyance under this subsection may be made, except a conveyance under paragraph (a) or paragraph (c), the department shall first afford a right of first refusal to the previous property owner for the department’s current estimate of value of the property. The right of first refusal must be made in writing and sent to the previous owner via certified mail or hand delivery, effective upon receipt. The right of first refusal must provide the previous owner with a minimum of 30 days to exercise the right in writing and must be sent to the originator of the offer by certified mail or hand delivery, effective upon dispatch. If the previous owner exercises his or her right of first refusal, the previous owner has a minimum of 90 days to close on the property. The right of first refusal set forth in this subsection may not be required for the disposal of property acquired more than 10 years before the date of disposition by the department.
(a) If the property has been donated to the state for transportation purposes and a transportation facility has not been constructed for at least 5 years, plans have not been prepared for the construction of such facility, and the property is not located in a transportation corridor, the governmental entity may authorize reconveyance of the donated property for no consideration to the original donor or the donor’s heirs, successors, assigns, or representatives.
(b) If the property is to be used for a public purpose, including, but not limited to, affordable housing as provided in ss. 125.379 and 166.0451, the property may be conveyed without consideration to a governmental entity.
(c) If the property was originally acquired specifically to provide replacement housing for persons displaced by transportation projects, the department may negotiate for the sale of such property as replacement housing. As compensation, the state shall receive at least its investment in such property or the department’s current estimate of value, whichever is lower. It is expressly intended that this benefit be extended only to persons actually displaced by the project. Dispositions to any other person must be for at least the department’s current estimate of value.
(d) If the department determines that the property requires significant costs to be incurred or that continued ownership of the property exposes the department to significant liability risks, the department may use the projected maintenance costs over the next 10 years to offset the property’s value in establishing a value for disposal of the property, even if that value is zero.
(e) If, at the discretion of the department, a sale to a person other than an abutting property owner would be inequitable, the property may be sold to the abutting owner for the department’s current estimate of value.
(5) The department may convey a leasehold interest for commercial or other purposes, in the name of the state, to any land, building, or other property, real or personal, which was acquired under subsection (1). However, a lease may not be entered into at a price less than the department’s current estimate of value. The department’s estimate of value shall be prepared in accordance with department procedures, guidelines, and rules for valuation of real property, the cost of which shall be paid by the party seeking the lease of the property.
(a) A lease may be accomplished through negotiations, sealed competitive bids, auction, or any other means the department deems to be in its best interest. The department may allow an outdoor advertising sign to remain on the property acquired or be relocated on department property. This subsection shall not cause a sign to be considered a nonconforming sign pursuant to chapter 479.
(b) If, at the discretion of the department, a lease to a person other than an abutting property owner or tenant with a leasehold interest in the abutting property would be inequitable, the property may be leased to the abutting owner or tenant for at least the department’s current estimate of value.
(c) A lease signed pursuant to paragraph (a) may not be for more than 5 years; however, the department may renegotiate or extend such a lease for an additional 5 years as the department deems appropriate.
(d) Each lease shall provide that, unless otherwise directed by the lessor, any improvements made to the property during the lease shall be removed at the lessee’s expense.
(e) If property is to be used for a public purpose, the property may be leased without consideration to a governmental entity. A lease for a public purpose is exempt from the term limits in paragraph (c).
(f) Paragraphs (c) and (e) do not apply to leases entered into pursuant to s. 260.0161(3), except as provided in such a lease.
(g) A lease executed under this subsection may not be used by the lessee to establish the standing required under s. 73.071(3)(b) if the business had not been established for the specified number of years on the date title passed to the department.
(h) The department may enter into a long-term lease without compensation with a public port listed in s. 403.021(9)(b) for rail corridors used for the operation of a short-line railroad to the port.
(6) This chapter does not prevent the joint use of right-of-way for alternative modes of transportation if the joint use does not impair the integrity and safety of the transportation facility.
(7) The department shall prepare the estimate of value provided under subsection (4) in accordance with department procedures, guidelines, and rules for valuation of real property. If the value of the property is greater than $50,000, as determined by the department estimate, the sale must be at a negotiated price of at least the estimate of value as determined by an appraisal prepared in accordance with department procedures, guidelines, and rules for valuation of real property, the cost of which shall be paid by the party seeking the purchase of the property. If the estimated value is $50,000 or less, the department may use a department staff appraiser or obtain an independent appraisal.
(8) As used in this section, the term “due advertisement” means an advertisement in a newspaper of general circulation in the area of the improvements of at least 14 calendar days before the date of the receipt of bids or the date on which a public auction is to be held.
(9) The department, with the approval of the Chief Financial Officer, may disburse state funds for real estate closings in a manner consistent with good business practices and in a manner minimizing costs and risks to the state.
(10) The department may purchase title insurance if it determines that such insurance is necessary to protect the public’s investment in property being acquired for transportation purposes. The department shall adopt procedures to be followed in making the determination to purchase title insurance for a particular parcel or group of parcels which, at a minimum, shall specify criteria that the parcels must meet.
(11) This section does not modify the requirements of s. 73.013.
History.—s. 104, ch. 29965, 1955; s. 1, ch. 61-430; s. 1, ch. 65-48; s. 1, ch. 65-33; ss. 23, 35, ch. 69-106; s. 2, ch. 77-44; s. 1, ch. 77-244; s. 1, ch. 78-282; s. 141, ch. 79-400; s. 2, ch. 82-36; s. 163, ch. 84-309; s. 16, ch. 88-168; s. 5, ch. 89-232; s. 78, ch. 90-136; s. 112, ch. 92-152; ss. 39, 40, ch. 93-164; s. 24, ch. 94-237; s. 968, ch. 95-148; s. 51, ch. 96-323; s. 15, ch. 97-280; s. 23, ch. 99-385; s. 54, ch. 2000-152; s. 373, ch. 2003-261; s. 12, ch. 2014-223; s. 4, ch. 2021-195; s. 1, ch. 2023-116.
337.2505 Donations for landscape projects.—The Department of Transportation is authorized to accept donations of plans, materials, installation, and maintenance for landscape projects on the State Highway System.
(1) The department shall adopt rules for review and permitting of landscape donations. The rules must include, but are not limited to, an examination of the donation’s aesthetic value, feasibility of installation and maintenance, compliance with state and federal regulations, and requirements for a maintenance plan.
(2) The department may place signs at the site of donated landscaping where the donation encompasses materials and their installation and maintenance. Department rules shall provide for the type and size of such signs.
History.—s. 6, ch. 92-152.
337.251 Lease of property for joint public-private development and areas above or below department property.—
(1) The department may lease to public agencies or private entities, for a term not to exceed 99 years, the use of department property, including rights-of-way, for joint public-private transportation purposes to further economic development in this state and generate revenue for transportation. The department may also lease the use of areas above or below state highways or other transportation facilities for commercial purposes. Leases under this section are subject to any reservations, restrictions, or conditions necessary to ensure adequate protection for the safe and efficient operation and maintenance of all transportation and utility facilities, the adequacy of traffic flow, and the full use of existing and future state transportation facilities. Such joint public-private use or commercial use of property may not interfere with the primary state transportation needs or present or future utility needs for that property nor be contrary to the best interests of the public. The department may not lease any such property if the proposed use conflicts with zoning or land development codes of any affected local government. The department shall, prior to entering into such lease, determine that the property subject to the lease has a permanent transportation use related to the responsibilities of the department, has the potential for such future transportation uses, or constitutes airspace or subsurface rights attached to property having such uses, and is therefore not available for sale as surplus property.
(2) The department may request proposals for the lease of such property or, if the department receives a proposal for a lease of a particular department property which it desires to consider, the department shall publish a notice in a newspaper of general circulation at least once a week for 2 weeks stating that it has received the proposal and will accept other proposals for lease of such property for 120 days after the date of publication. A copy of the notice must be mailed to each local government in the affected area. The department shall establish by rule an application fee for the submission of proposals pursuant to this section. The fee must be sufficient to pay the anticipated costs of evaluating the proposals. The department may engage the services of private consultants to assist in the evaluations. Before approval, the department shall determine that the proposed lease:
(a) Is in the public’s best interest;
(b) Does not require that state funds be used; and
(c) Has adequate safeguards in place to ensure that additional costs are not borne and service disruptions are not experienced by the traveling public and residents of the state in the event of default by the private lessee or upon termination or expiration of the lease.
(3) A proposal must be selected by the department based on competitive bidding, except that the department may consider other relevant factors specified in the request for proposals. The department may consider such factors as the value of property exchanges, the cost of construction, and other recurring costs for the benefit of the department by the lessee in lieu of direct revenue to the department if such other factors are of equal value including innovative proposals to involve minority businesses. The department may name a board of advisers which may be composed of accountants, real estate appraisers, design engineers, or other experts experienced in the type of development proposed. The board of advisers shall review the feasibility of the proposals, recommend acceptance or rejection of each proposal, and rank each feasible proposal in the order of technical feasibility and benefit provided to the department. The board of advisers shall be reasonably compensated for the services provided and all department costs for evaluating the proposals shall be reimbursed from a proposal application fee to be set by the department and paid by the applicants. The board of advisers shall not be subject to selection under the provisions of chapter 287.
(4) The requirements of this section apply to complex lease transactions involving extensive capital improvements by the lessee or provisions for exchange of goods or services by the lessee in lieu of cash and do not affect the requirements for other types of leases set forth in s. 337.25(5).
(5) The department may utilize leaseback or other joint public-private uses of property in lieu of full or partial compensation to a property owner for property acquired by eminent domain or to a landowner who donates property to the department, without competitive proposals and selection, if such use is acceptable to the property owner in lieu of other compensation and such use does not interfere with the public transportation purpose for which the property was acquired.
(6) This section does not require right-of-way lease arrangements for facilities of utilities which provide water, sewer, gas, telecommunication, or electric services for which utilities may obtain permits from the department.
(7) The department shall be indemnified by a lessee for liability which arises from construction on or the use of department property by the lessee. Mortgages or other liens or encumbrances may not attach to department property as a result of the financing, construction, or use of the property by the lessee. Improvements constructed on the property by the lessee shall revert to the department upon expiration of the lease.
(8) Revenue derived from a joint public-private use shall be deposited in the State Transportation Trust Fund.
(9) A fixed-guideway transportation system authorized by the department to be wholly or partially within the department’s right-of-way pursuant to a lease granted under this section may operate at any safe speed.
(10) The department may adopt rules to administer the provisions of this section.
History.—s. 7, ch. 90-227; s. 27, ch. 95-257; s. 38, ch. 96-323; s. 24, ch. 99-385; s. 53, ch. 2002-20; s. 9, ch. 2005-281; s. 13, ch. 2014-223.
337.26 Execution and effect of instruments of sale, lease, or conveyance executed by department.—
(1) An instrument of sale, lease, or conveyance executed in the name of the department, and signed by the department’s chief administrative officer of the district in which the property is located, or, if the property is located on the turnpike system, by the chief administrative officer of the Office of Florida Turnpike, when such authority has been delegated by the head of the department, with the corporate seal of the department affixed thereto, is effective to pass the title or interest of the state in the property conveyed.
(2) No instrument of conveyance by the department shall warrant the title to any property sold, leased, or conveyed.
History.—s. 105, ch. 29965, 1955; s. 17, ch. 57-318; ss. 23, 35, ch. 69-106; s. 164, ch. 84-309; s. 17, ch. 88-168; s. 131, ch. 92-152.
337.27 Exercise of power of eminent domain by department; procedure; title; cost.—
(1) The power of eminent domain is vested in the department to condemn all necessary lands and property, including rights of access, air, view, and light, whether public or private, for the purpose of securing and utilizing transportation rights-of-way, including, but not limited to, any lands reasonably necessary for securing applicable permits, areas necessary for management of access, borrow pits, drainage ditches, water retention areas, rest areas, replacement access for landowners whose access is impaired due to the construction of a facility, and replacement rights-of-way for relocated rail and utility facilities; for existing, proposed, or anticipated transportation facilities on the State Highway System or State Park Road System; or in a transportation corridor designated by the department; or for the purposes of screening, relocation, removal, or disposal of junkyards and scrap metal processing facilities. The department shall also have the power to condemn any material and property necessary for such purposes. The secretary of the Department of Transportation may delegate the authority to execute eminent domain resolutions to the department’s chief administrative officer of the district in which the property is located, or to the chief administrative officer of the Office of Florida Turnpike if the property is to be acquired for a turnpike system project.
(2) Title to any land acquired in the name of the department vests in the state.
(3) The department is authorized to pay the judgment or compensation, including deposits required, awarded in any such proceedings out of any funds available to the department for the maintenance or construction of any transportation facility on the State Highway System, on the State Park Road System, or in a transportation corridor designated by the department.
(4) When the department acquires property for a transportation facility or in a transportation corridor through the exercise of eminent domain authority, or by purchase or donation, it is not subject to any liability imposed by chapter 376 or chapter 403 for preexisting soil or groundwater contamination due solely to its ownership. This section does not affect the rights or liabilities of any past or future owners of the acquired property nor does it affect the liability of any governmental entity for the results of its actions which create or exacerbate a pollution source. The department and the Department of Environmental Protection may enter into interagency agreements for the performance, funding, and reimbursement of the investigative and remedial acts necessary for property acquired by the department.
History.—s. 106, ch. 29965, 1955; s. 18, ch. 57-318; ss. 23, 35, ch. 69-106; s. 1, ch. 80-312; s. 165, ch. 84-309; s. 2, ch. 84-319; s. 3, ch. 87-164; s. 1, ch. 87-242; s. 18, ch. 88-168; s. 6, ch. 89-232; s. 132, ch. 92-152; s. 166, ch. 94-356; s. 64, ch. 99-385.
337.273 Transportation corridors.—
(1) It is hereby found and declared that:
(a) Immediate and decisive action must be taken to plan, designate, and develop transportation corridors within this state in order that the public health, safety, and welfare may be protected, preserved, and improved by planning for future growth, coordinating land use and transportation planning, and complying with the concurrency requirements of chapter 163.
(b) Traffic congestion and facility overcrowding on the State Highway System constitutes a serious and growing problem; impedes the development of an effective transportation system; results in increased incidents of traffic accidents, personal injury, and property damage or loss; causes environmental degradation; impedes sound economic growth; impairs effective growth management, including the ability to meet concurrency requirements and coordinate land use decisions and transportation planning; discourages tourism; aggravates social discord; increases maintenance costs; shortens the effective life of the transportation facility; delays public evacuation for natural storms and emergencies; impairs national defense and disaster response readiness; delays response time for emergency vehicles; significantly increases public infrastructure needs and associated public costs, such as police, fire, accident, medical, and hospital costs; and otherwise is injurious to the public health, safety, and welfare.
(c) The designation and management of transportation corridors and the planning and development of transportation facilities within transportation corridors will substantially assist in allowing government to alleviate traffic congestion and transportation facility overcrowding, aid in the development of an effective transportation system that is coordinated with land use planning, assist in planning for future growth, enable compliance with concurrency requirements, and alleviate the heretofore described health, safety, and welfare liabilities to the public.
(d) The designation and management of transportation corridors can best be achieved through the inclusion of transportation corridors in the local government comprehensive plans that are developed, reviewed, and adopted pursuant to chapter 163, in order to ensure comprehensive planning for future development and growth, improved coordination between land use and transportation planning, and compliance with concurrency requirements.
(2) It is further found and declared that:
(a) Investments in transportation corridors cannot be adequately coordinated with land use decisions without timely preservation, management, or acquisition of property necessary to accommodate existing and planned transportation facilities within the corridor.
(b) The inability to timely protect or acquire property necessary to accommodate a transportation facility in a transportation corridor constitutes an economic, health, safety, and welfare liability that imposes increasingly onerous burdens on public revenues, seriously impedes the ability to plan for future growth, substantially impairs or arrests sound growth, impedes the provision of transportation infrastructure concurrent with the impact of development, retards the provision of an adequate transportation system for the people in the state, aggravates traffic problems, and substantially hampers the elimination of traffic hazards and the improvement of traffic facilities.
(c) When development, building, or other intensification of land uses occur within the area of right-of-way needed for transportation facilities, the subsequent public acquisition of property results in disruption of neighborhoods, residences, and businesses; relocation of people and property; interference with utility facilities; and substantial additional costs to property owners, business owners, and public agencies for services, planning, permitting, and zoning.
(d) The prevention and elimination of traffic congestion on the State Highway System and the protection, management, and early acquisition of property to accommodate future transportation facilities is a matter of state policy and state concern in order that the state, counties, and municipalities shall not continue to consume an excessive proportion of limited resources on the extra services required for police, fire, accident, hospitalization, and other forms of public protection services and facilities as a result of inadequate transportation facilities.
(3) It is the intent of the Legislature that governmental police powers be utilized to the greatest extent possible by each governmental entity, and by two or more entities through corridor management agreements, to manage land uses necessary for transportation corridors; that property acquisition by donation, purchase, or eminent domain occur as far in advance of construction need as possible; and that property, needed to manage transportation corridors, be acquired and retained for future use to avoid the public liabilities for health, safety, and welfare heretofore outlined.
(4) It is recognized by the Legislature that advance acquisition of property to manage land uses in transportation corridors for future use will, of necessity, require acquisition without design plans and profiles, project development, and construction information; and it is intended by the Legislature that such advance acquisition, including acquisition utilizing the power of eminent domain, must nevertheless occur to avoid the social, economic, health, safety, and welfare liabilities heretofore declared.
(5) When lands and property in a transportation corridor are acquired pursuant to the eminent domain powers granted by s. 337.27(1), public purpose and necessity may be demonstrated through the use of typical design, construction plans or profiles, and one or more of the following: anticipated trends in such areas as demographic and other growth patterns, land use and development patterns, traffic projections, expected utility needs, or future anticipated mass-transit requirements. Immediate availability of construction funds and applicable permits shall not be required to support such showing of public purpose and necessity.
(6) A local government may designate a transportation corridor by including the corridor in the entity’s comprehensive plan traffic circulation or transportation element. A transportation management ordinance may be adopted for designated transportation corridors. The transportation corridor management ordinance should contain the criteria to manage the land uses within and adjacent to the transportation corridor, the types of restrictions on nonresidential and residential construction within the designated corridor, identification of permitted land uses within the designated corridor, a public notification process, a variance and appeal process, and an intergovernmental coordination process that provides for the coordinated management of transportation corridors that cross jurisdictional boundaries with the plans of adjacent jurisdictions. Local governments may adopt such additional ordinances and regulations as necessary to manage designated transportation corridors.
History.—s. 20, ch. 88-168; s. 110, ch. 92-152; s. 41, ch. 95-257.
337.2735 Recording of municipal maps of reservation for transportation corridors and transportation facilities; establishment of building setback lines; restrictions on issuance of development permits; hearings.—
(1) The governing body of a municipality may approve maps of reservation for any transportation facility or transportation corridor within the municipality’s jurisdiction. Any such maps shall delineate the limits of the transportation corridor or of the proposed rights-of-way for the eventual widening of an existing or proposed transportation facility. Before recording such map, the municipality shall advertise and hold a public hearing and shall notify all property owners of record within the limits of the transportation corridor or rights-of-way of the transportation facility shown on the proposed map, as recorded in the property appraiser’s office, by mail at least 20 days prior to the date set for the hearing. After the public hearing, the municipality shall send the map to the clerk of the court of the county, who shall forthwith record the map in accordance with chapter 177 in the public land records of the county. Minor amendments to such maps are not subject to the notice and public hearing provisions of this section, except that property owners directly affected by changes in a minor amendment must be notified by mail. Minor amendments are defined as those changes which affect less than 5 percent of the total area within the map.
(2) Upon recording, such map shall establish a building setback line from the centerline of any transportation facility and an area of proposed right-of-way and shall cite the ordinance which defines building restrictions for such maps.
(3) Prior to filing any map pursuant to this section, a municipality shall have adopted an ordinance defining the types of restrictions on nonresidential and residential construction within the proposed rights-of-way and building setback lines. In no case, however, shall said ordinance restrict the renovation of an existing residential structure when the renovation does not exceed 20 percent of the appraised value of the structure.
(4) Upon petition by any property owner of record within the limits of the map alleging that such property regulation is unreasonable or arbitrary and that its effect is to deny a substantial portion of the beneficial use of such property, the municipality shall hold a hearing. When such a hearing results in a finding in favor of the petitioning property owner, the municipality shall have 180 days from the date of such finding to acquire such property, to amend the map, to withdraw the map, to issue the permit, or to file appropriate proceedings. Either party may seek appellate review.
(5) This section shall be regarded as supplemental and additional to the powers conferred upon municipalities by s. 2, Art. VIII of the State Constitution and by law and shall not be regarded as in derogation of any powers now existing.
History.—s. 6, ch. 88-168.
337.274 Authority of department agent or employee to enter lands, waters, and premises of another in the performance of duties.—The department and its authorized agents and employees are authorized to enter upon any lands, waters, and premises, upon giving reasonable notice to the landowner, for the purpose of making surveys, soundings, drillings, appraisals, environmental assessments, archaeological assessments, and examinations necessary to perform its duties and functions; and any such entry shall not be deemed a trespass or an entry that would constitute a taking in an eminent domain proceeding. The department shall make reimbursement for any actual damages to such lands, water, and premises as a result of such activities.
History.—s. 2, ch. 84-319; s. 7, ch. 89-232; s. 113, ch. 92-152.
337.276 Issuance of bonds for right-of-way land acquisition and state bridge construction.—
(1) The Division of Bond Finance of the State Board of Administration is authorized, in accordance with s. 215.605, to issue state bonds on behalf of the department to finance right-of-way land acquisition and to finance state bridge construction. The total amount of bonds to be issued under this section shall be limited by the debt service requirements of the bonds issued, and such requirements shall not exceed 90 percent of the pledged revenue authorized to be transferred pursuant to s. 206.46(2).
(2) If right-of-way purchased from the proceeds of such bonds is used for a revenue-producing facility, the owner of that facility may reimburse the Right-of-Way Acquisition and Bridge Construction Trust Fund in an amount equal to the cost of acquiring that right-of-way.
History.—s. 34, ch. 90-136; s. 114, ch. 92-152; s. 282, ch. 92-279; s. 55, ch. 92-326; s. 12, ch. 93-164; s. 1, ch. 94-237; s. 42, ch. 95-257; s. 138, ch. 96-320; s. 26, ch. 96-323.
337.29 Vesting of title to roads; liability for torts.—
(1) Title to all roads designated in the State Highway System or State Park Road System shall be in the state, unless otherwise provided herein.
(2) Upon the vesting of title to any lands for highway purposes in the state, local governmental entities shall forthwith issue a deed or right-of-way map to the state covering such lands, which shall be duly recorded. Recordation of deeds or right-of-way maps shall also be effected upon acquisition of any lands by the department.
(3) Title to all roads transferred in accordance with s. 335.0415 shall be in the governmental entity to which such roads have been transferred, upon the recording of a deed or a right-of-way map by the appropriate governmental entity in the public land records of the county or counties in which such rights-of-way are located. To the extent that sovereign immunity has been waived, liability for torts shall be in the governmental entity having operation and maintenance responsibility as provided in s. 335.0415. Except as otherwise provided by law, a municipality shall have the same governmental, corporate, and proprietary powers with relation to any public road or right-of-way within the municipality which has been transferred to another governmental entity pursuant to s. 335.0415 that the municipality has with relation to other public roads and rights-of-way within the municipality.
History.—s. 108, ch. 29965, 1955; ss. 23, 35, ch. 69-106; s. 16, ch. 77-165; s. 5, ch. 77-416; s. 2, ch. 78-285; s. 169, ch. 84-309; s. 85, ch. 99-385; s. 34, ch. 2012-174.
337.401 Use of right-of-way for utilities subject to regulation; permit; fees.—
(1)(a) The department and local governmental entities, referred to in this section and in ss. 337.402-337.404 as the “authority,” that have jurisdiction and control of public roads or publicly owned rail corridors are authorized to prescribe and enforce reasonable rules or regulations with reference to the placing and maintaining across, on, or within the right-of-way limits of any road or publicly owned rail corridors under their respective jurisdictions any electric transmission, voice, telegraph, data, or other communications services lines or wireless facilities; pole lines; poles; railways; ditches; sewers; water, heat, or gas mains; pipelines; fences; gasoline tanks and pumps; or other structures referred to in this section and in ss. 337.402-337.404 as the “utility.” The department may enter into a permit-delegation agreement with a governmental entity if issuance of a permit is based on requirements that the department finds will ensure the safety and integrity of facilities of the Department of Transportation; however, the permit-delegation agreement does not apply to facilities of electric utilities as defined in s. 366.02(4).
(b) For aerial and underground electric utility transmission lines designed to operate at 69 or more kilovolts that are needed to accommodate the additional electrical transfer capacity on the transmission grid resulting from new base-load generating facilities, the department’s rules shall provide for placement of and access to such transmission lines adjacent to and within the right-of-way of any department-controlled public roads, including longitudinally within limited access facilities where there is no other practicable alternative available, to the greatest extent allowed by federal law, if compliance with the standards established by such rules is achieved. Without limiting or conditioning the department’s jurisdiction or authority described in paragraph (a), with respect to limited access right-of-way, such rules may include, but need not be limited to, that the use of the right-of-way for longitudinal placement of electric utility transmission lines is reasonable based upon a consideration of economic and environmental factors, including, without limitation, other practicable alternative alignments, utility corridors and easements, impacts on adjacent property owners, and minimum clear zones and other safety standards, and further provide that placement of the electric utility transmission lines within the department’s right-of-way does not interfere with operational requirements of the transportation facility or planned or potential future expansion of such transportation facility. If the department approves longitudinal placement of electric utility transmission lines in limited access facilities, compensation for the use of the right-of-way is required. Such consideration or compensation paid by the electric utility in connection with the department’s issuance of a permit does not create any property right in the department’s property regardless of the amount of consideration paid or the improvements constructed on the property by the utility. Upon notice by the department that the property is needed for expansion or improvement of the transportation facility, the electric utility transmission line will be removed or relocated at the electric utility’s sole expense. The electric utility shall pay to the department reasonable damages resulting from the utility’s failure or refusal to timely remove or relocate its transmission lines. The rules to be adopted by the department may also address the compensation methodology and removal or relocation. As used in this subsection, the term “base-load generating facilities” means electric power plants that are certified under part II of chapter 403.
(2) The authority may grant to any person who is a resident of this state, or to any corporation which is organized under the laws of this state or licensed to do business within this state, the use of a right-of-way for the utility in accordance with such rules or regulations as the authority may adopt. A utility may not be installed, located, or relocated unless authorized by a written permit issued by the authority. However, for public roads or publicly owned rail corridors under the jurisdiction of the department, a utility relocation schedule and relocation agreement may be executed in lieu of a written permit. The permit must require the permitholder to be responsible for any damage resulting from the issuance of such permit. The authority may initiate injunctive proceedings as provided in s. 120.69 to enforce provisions of this subsection or any rule or order issued or entered into pursuant thereto. A permit application required under this subsection by a county or municipality having jurisdiction and control of the right-of-way of any public road must be processed and acted upon in accordance with the timeframes provided in subparagraphs (7)(d)7., 8., and 9.
(3)(a) Because of the unique circumstances applicable to providers of communications services, including, but not limited to, the circumstances described in paragraph (e) and the fact that federal and state law require the nondiscriminatory treatment of providers of telecommunications services, and because of the desire to promote competition among providers of communications services, it is the intent of the Legislature that municipalities and counties treat providers of communications services in a nondiscriminatory and competitively neutral manner when imposing rules or regulations governing the placement or maintenance of communications facilities in the public roads or rights-of-way. Rules or regulations imposed by a municipality or county relating to providers of communications services placing or maintaining communications facilities in its roads or rights-of-way must be generally applicable to all providers of communications services, taking into account the distinct engineering, construction, operation, maintenance, public works, and safety requirements of the provider’s facilities, and, notwithstanding any other law, may not require a provider of communications services to apply for or enter into an individual license, franchise, or other agreement with the municipality or county as a condition of placing or maintaining communications facilities in its roads or rights-of-way. In addition to other reasonable rules or regulations that a municipality or county may adopt relating to the placement or maintenance of communications facilities in its roads or rights-of-way under this subsection or subsection (7), a municipality or county may require a provider of communications services that places or seeks to place facilities in its roads or rights-of-way to register with the municipality or county. To register, a provider of communications services may be required only to provide its name; the name, address, and telephone number of a contact person for the registrant; the number of the registrant’s current certificate of authorization issued by the Florida Public Service Commission, the Federal Communications Commission, or the Department of State; a statement of whether the registrant is a pass-through provider as defined in subparagraph (6)(a)1.; the registrant’s federal employer identification number; and any required proof of insurance or self-insuring status adequate to defend and cover claims. A municipality or county may not require a registrant to renew a registration more frequently than every 5 years but may require during this period that a registrant update the registration information provided under this subsection within 90 days after a change in such information. A municipality or county may not require the registrant to provide an inventory of communications facilities, maps, locations of such facilities, or other information by a registrant as a condition of registration, renewal, or for any other purpose; provided, however, that a municipality or county may require as part of a permit application that the applicant identify at-grade communications facilities within 50 feet of the proposed installation location for the placement of at-grade communications facilities. A municipality or county may not require a provider to pay any fee, cost, or other charge for registration or renewal thereof. It is the intent of the Legislature that the placement, operation, maintenance, upgrading, and extension of communications facilities not be unreasonably interrupted or delayed through the permitting or other local regulatory process. Except as provided in this chapter or otherwise expressly authorized by chapter 202, chapter 364, or chapter 610, a municipality or county may not adopt or enforce any ordinance, regulation, or requirement as to the placement or operation of communications facilities in a right-of-way by a communications services provider authorized by state or local law to operate in a right-of-way; regulate any communications services; or impose or collect any tax, fee, cost, charge, or exaction for the provision of communications services over the communications services provider’s communications facilities in a right-of-way.
(b) Registration described in paragraph (a) does not establish a right to place or maintain, or priority for the placement or maintenance of, a communications facility in roads or rights-of-way of a municipality or county. Each municipality and county retains the authority to regulate and manage municipal and county roads or rights-of-way in exercising its police power, subject to the limitations imposed in this section and chapters 202 and 610. Any rules or regulations adopted by a municipality or county which govern the occupation of its roads or rights-of-way by providers of communications services must be related to the placement or maintenance of facilities in such roads or rights-of-way, must be reasonable and nondiscriminatory, and may include only those matters necessary to manage the roads or rights-of-way of the municipality or county.
(c) Any municipality or county that, as of January 1, 2019, elected to require permit fees from any provider of communications services that uses or occupies municipal or county roads or rights-of-way pursuant to former paragraph (c) or former paragraph (j), Florida Statutes 2018, may continue to require and collect such fees. A municipality or county that elected as of January 1, 2019, to require permit fees may elect to forego such fees as provided herein. A municipality or county that elected as of January 1, 2019, not to require permit fees may not elect to impose permit fees. All fees authorized under this paragraph must be reasonable and commensurate with the direct and actual cost of the regulatory activity, including issuing and processing permits, plan reviews, physical inspection, and direct administrative costs; must be demonstrable; and must be equitable among users of the roads or rights-of-way. A fee authorized under this paragraph may not be offset against the tax imposed under chapter 202; include the costs of roads or rights-of-way acquisition or roads or rights-of-way rental; include any general administrative, management, or maintenance costs of the roads or rights-of-way; or be based on a percentage of the value or costs associated with the work to be performed on the roads or rights-of-way. In an action to recover amounts due for a fee not authorized under this paragraph, the prevailing party may recover court costs and attorney fees at trial and on appeal. In addition to the limitations set forth in this section, a fee levied by a municipality or charter county under this paragraph may not exceed $100. However, permit fees may not be imposed with respect to permits that may be required for service drop lines not required to be noticed under s. 556.108(5) or for any activity that does not require the physical disturbance of the roads or rights-of-way or does not impair access to or full use of the roads or rights-of-way, including, but not limited to, the performance of service restoration work on existing facilities, extensions of such facilities for providing communications services to customers, and the placement of micro wireless facilities in accordance with subparagraph (7)(e)3.
1. If a municipality or charter county elects to not require permit fees, the total rate for the local communications services tax as computed under s. 202.20 for that municipality or charter county may be increased by ordinance or resolution by an amount not to exceed a rate of 0.12 percent.
2. If a noncharter county elects to not require permit fees, the total rate for the local communications services tax as computed under s. 202.20 for that noncharter county may be increased by ordinance or resolution by an amount not to exceed a rate of 0.24 percent, to replace the revenue the noncharter county would otherwise have received from permit fees for providers of communications services.
(d) In addition to any other notice requirements, a municipality must provide to the Secretary of State, at least 10 days prior to consideration on first reading, notice of a proposed ordinance governing a telecommunications company placing or maintaining telecommunications facilities in its roads or rights-of-way. In addition to any other notice requirements, a county must provide to the Secretary of State, at least 15 days prior to consideration at a public hearing, notice of a proposed ordinance governing a telecommunications company placing or maintaining telecommunications facilities in its roads or rights-of-way. The notice required by this paragraph must be published by the Secretary of State on a designated Internet website. The failure of a municipality or county to provide such notice does not render the ordinance invalid, provided that enforcement of such ordinance must be suspended until 30 days after the municipality or county provides the required notice.
(e) The authority of municipalities and counties to require franchise fees from providers of communications services, with respect to the provision of communications services, is specifically preempted by the state because of unique circumstances applicable to providers of communications services when compared to other utilities occupying municipal or county roads or rights-of-way. Providers of communications services may provide similar services in a manner that requires the placement of facilities in municipal or county roads or rights-of-way or in a manner that does not require the placement of facilities in such roads or rights-of-way. Although similar communications services may be provided by different means, the state desires to treat providers of communications services in a nondiscriminatory manner and to have the taxes, franchise fees, and other fees, costs, and financial or regulatory exactions paid by or imposed on providers of communications services be competitively neutral. Municipalities and counties retain all existing authority, if any, to collect franchise fees from users or occupants of municipal or county roads or rights-of-way other than providers of communications services, and the provisions of this subsection shall have no effect upon this authority. The provisions of this subsection do not restrict the authority, if any, of municipalities or counties or other governmental entities to receive reasonable rental fees based on fair market value for the use of public lands and buildings on property outside the public roads or rights-of-way for the placement of communications antennas and towers.
(f) Except as expressly allowed or authorized by general law and except for the rights-of-way permit fees subject to paragraph (c), a municipality or county may not levy on a provider of communications services a tax, fee, or other charge or imposition for operating as a provider of communications services within the jurisdiction of the municipality or county which is in any way related to using its roads or rights-of-way. A municipality or county may not require or solicit in-kind compensation, except as otherwise provided in s. 202.24(2)(c)8., provided that the in-kind compensation is not a franchise fee under federal law. Nothing in this paragraph impairs the authority of a municipality or county to request public, educational, or governmental access channels pursuant to s. 610.109. Nothing in this paragraph shall impair any ordinance or agreement in effect on May 22, 1998, or any voluntary agreement entered into subsequent to that date, which provides for or allows in-kind compensation by a telecommunications company.
(g) A municipality or county may not use its authority over the placement of facilities in its roads and rights-of-way as a basis for asserting or exercising regulatory control over a provider of communications services regarding matters within the exclusive jurisdiction of the Florida Public Service Commission or the Federal Communications Commission, including, but not limited to, the operations, systems, equipment, technology, qualifications, services, service quality, service territory, and prices of a provider of communications services. A municipality or county may not require any permit for the maintenance, repair, replacement, extension, or upgrade of existing aerial wireline communications facilities on utility poles or for aerial wireline facilities between existing wireline communications facility attachments on utility poles by a communications services provider. However, a municipality or county may require a right-of-way permit for work that involves excavation, closure of a sidewalk, or closure of a vehicular lane or parking lane, unless the provider is performing service restoration to existing facilities. A permit application required by an authority under this section for the placement of communications facilities must be processed and acted upon consistent with the timeframes provided in subparagraphs (7)(d)7., 8., and 9. In addition, a municipality or county may not require any permit or other approval, fee, charge, or cost, or other exaction for the maintenance, repair, replacement, extension, or upgrade of existing aerial lines or underground communications facilities located on private property outside of the public rights-of-way. As used in this section, the term “extension of existing facilities” includes those extensions from the rights-of-way into a customer’s private property for purposes of placing a service drop or those extensions from the rights-of-way into a utility easement to provide service to a discrete identifiable customer or group of customers.
(h) A provider of communications services that has obtained permission to occupy the roads or rights-of-way of an incorporated municipality pursuant to s. 362.01 or that is otherwise lawfully occupying the roads or rights-of-way of a municipality or county shall not be required to obtain consent to continue such lawful occupation of those roads or rights-of-way; however, nothing in this paragraph shall be interpreted to limit the power of a municipality or county to adopt or enforce reasonable rules or regulations as provided in this section and consistent with chapters 202, 364, and 610. Any such rules or regulations must be in writing, and registered providers of communications services in the municipality or county must be given at least 60 days’ advance written notice of any changes to the rules and regulations.
(i) Except as expressly provided in this section, this section does not modify the authority of municipalities and counties to levy the tax authorized in chapter 202 or the duties of providers of communications services under ss. 337.402-337.404. This section does not apply to building permits, pole attachments, or private roads, private easements, and private rights-of-way.
(j) Notwithstanding the provisions of s. 202.19, when a local communications services tax rate is changed as a result of an election made or changed under this subsection, such rate may not be rounded to tenths.
(4) As used in this section, “communications services” and “dealer” have the same meanings ascribed in chapter 202, and “cable service” has the same meaning ascribed in 47 U.S.C. s. 522, as amended.
(5) This section, except subsections (1) and (2) and paragraph (3)(g), does not apply to the provision of pay telephone service on public, municipal, or county roads or rights-of-way.
(6)(a) As used in this subsection, the following definitions apply:
1.a. A “pass-through provider” is any person who places or maintains a communications facility in the roads or rights-of-way of a municipality or county that levies a tax pursuant to chapter 202 and who does not remit taxes imposed by that municipality or county pursuant to chapter 202.
b. Notwithstanding sub-subparagraph a., a person who does not remit taxes imposed by a municipality or county pursuant to chapter 202, but pursuant to s. 202.16(2) sells communications services for resale to a person who sells such services at retail or who integrates such services into communications services sold at retail in that municipality or county and who remits taxes imposed by that municipality or county pursuant to chapter 202, is not a pass-through provider.
2. A “communications facility” is a facility that may be used to provide communications services. Multiple cables, conduits, strands, or fibers located within the same conduit shall be considered one communications facility for purposes of this subsection.
(b) A municipality that levies a tax pursuant to chapter 202 may charge a pass-through provider that places or maintains a communications facility in the municipality’s roads or rights-of-way an annual amount not to exceed $500 per linear mile or portion thereof. A municipality’s roads or rights-of-way do not include roads or rights-of-way that extend in or through the municipality but are state, county, or another authority’s roads or rights-of-way.
(c) A county that levies a tax pursuant to chapter 202 may charge a pass-through provider that places or maintains a communications facility in the county’s roads or rights-of-way, including county roads or rights-of-way within a municipality in the county, an annual amount not to exceed $500 per linear mile or portion thereof. However, a county shall not impose a charge for any linear miles, or portions thereof, of county roads or rights-of-way where a communications facility is placed that extend through any municipality within the county to which the pass-through provider remits a tax imposed pursuant to chapter 202. A county’s roads or rights-of-way do not include roads or rights-of-way that extend in or through the county but are state, municipal, or another authority’s roads or rights-of-way.
(d) The amounts charged pursuant to this subsection shall be based on the linear miles of roads or rights-of-way where a communications facility is placed, not based on a summation of the lengths of individual cables, conduits, strands, or fibers. The amounts referenced in this subsection may be charged only once annually and only to one person annually for any communications facility. A municipality or county shall discontinue charging such amounts to a person that has ceased to be a pass-through provider. Any annual amounts charged shall be reduced for a prorated portion of any 12-month period during which the person remits taxes imposed by the municipality or county pursuant to chapter 202. Any excess amounts paid to a municipality or county shall be refunded to the person upon written notice of the excess to the municipality or county. A municipality or county may require a pass-through provider to provide an annual notarized statement identifying the total number of linear miles of pass-through facilities in the municipality’s or county’s rights-of-way. Upon request from a municipality or county, a pass-through provider must provide reasonable access to maps of pass-through facilities located in the rights-of-way of the municipality or county making the request. The scope of the request must be limited to only those maps of pass-through facilities from which the calculation of the linear miles of pass-through facilities in the rights-of-way can be determined. The request must be accompanied by an affidavit that the person making the request is authorized by the municipality or county to review tax information related to the revenue and mileage calculations for pass-through providers. A request may not be made more than once annually to a pass-through provider.
(e) This subsection does not alter any provision of this section or s. 202.24 relating to taxes, fees, or other charges or impositions by a municipality or county on a dealer of communications services or authorize that any charges be assessed on a dealer of communications services, except as specifically set forth herein. A municipality or county may not charge a pass-through provider any amounts other than the charges under this subsection as a condition to the placement or maintenance of a communications facility in the roads or rights-of-way of a municipality or county by a pass-through provider, except that a municipality or county may impose permit fees on a pass-through provider consistent with paragraph (3)(c).
(f) The charges under this subsection do not apply to communications facilities placed in a municipality’s or county’s rights-of-way prior to the effective date of this subsection with permission from the municipality or county, if any was required, except to the extent the facilities of a pass-through provider were subject to per linear foot or mile charges in effect as of October 1, 2001, in which case the municipality or county may only impose on a pass-through provider charges consistent with paragraph (b) or paragraph (c) for such facilities. Notwithstanding the foregoing, this subsection does not impair any written agreement between a pass-through provider and a municipality or county imposing per linear foot or mile charges for communications facilities placed in municipal or county roads or rights-of-way that is in effect prior to the effective date of this subsection. Upon the termination or expiration of any such written agreement, any charges imposed must be consistent with this section.
(g) The charges authorized in this subsection shall not be applied with respect to any communications facility that is used exclusively for the internal communications of an electric utility or other person in the business of transmitting or distributing electric energy.
(7)(a) This subsection may be cited as the “Advanced Wireless Infrastructure Deployment Act.”
(b) As used in this subsection, the term:
1. “Antenna” means communications equipment that transmits or receives electromagnetic radio frequency signals used in providing wireless services.
2. “Applicable codes” means uniform building, fire, electrical, plumbing, or mechanical codes adopted by a recognized national code organization or local amendments to those codes enacted solely to address threats of destruction of property or injury to persons, and includes the National Electric Safety Code and the 2017 edition of the Florida Department of Transportation Utility Accommodation Manual.
3. “Applicant” means a person who submits an application and is a wireless provider.
4. “Application” means a request submitted by an applicant to an authority for a permit to collocate small wireless facilities or to place a new utility pole used to support a small wireless facility.
5. “Authority” means a county or municipality having jurisdiction and control of the rights-of-way of any public road. The term does not include the Department of Transportation. Rights-of-way under the jurisdiction and control of the department are excluded from this subsection.
6. “Authority utility pole” means a utility pole owned by an authority in the right-of-way. The term does not include a utility pole owned by a municipal electric utility, a utility pole used to support municipally owned or operated electric distribution facilities, or a utility pole located in the right-of-way within:
a. A retirement community that:
(I) Is deed restricted as housing for older persons as defined in s. 760.29(4)(b);
(II) Has more than 5,000 residents; and
(III) Has underground utilities for electric transmission or distribution.
b. A municipality that:
(I) Is located on a coastal barrier island as defined in s. 161.053(1)(b)3.;
(II) Has a land area of less than 5 square miles;
(III) Has less than 10,000 residents; and
(IV) Has, before July 1, 2017, received referendum approval to issue debt to finance municipal-wide undergrounding of its utilities for electric transmission or distribution.
7. “Collocate” or “collocation” means to install, mount, maintain, modify, operate, or replace one or more wireless facilities on, under, within, or adjacent to a wireless support structure or utility pole. The term does not include the installation of a new utility pole or wireless support structure in the public rights-of-way.
8. “FCC” means the Federal Communications Commission.
9. “Micro wireless facility” means a small wireless facility having dimensions no larger than 24 inches in length, 15 inches in width, and 12 inches in height and an exterior antenna, if any, no longer than 11 inches.
10. “Small wireless facility” means a wireless facility that meets the following qualifications:
a. Each antenna associated with the facility is located inside an enclosure of no more than 6 cubic feet in volume or, in the case of antennas that have exposed elements, each antenna and all of its exposed elements could fit within an enclosure of no more than 6 cubic feet in volume; and
b. All other wireless equipment associated with the facility is cumulatively no more than 28 cubic feet in volume. The following types of associated ancillary equipment are not included in the calculation of equipment volume: electric meters, concealment elements, telecommunications demarcation boxes, ground-based enclosures, grounding equipment, power transfer switches, cutoff switches, vertical cable runs for the connection of power and other services, and utility poles or other support structures.
11. “Utility pole” means a pole or similar structure that is used in whole or in part to provide communications services or for electric distribution, lighting, traffic control, signage, or a similar function. The term includes the vertical support structure for traffic lights but does not include a horizontal structure to which signal lights or other traffic control devices are attached and does not include a pole or similar structure 15 feet in height or less unless an authority grants a waiver for such pole.
12. “Wireless facility” means equipment at a fixed location which enables wireless communications between user equipment and a communications network, including radio transceivers, antennas, wires, coaxial or fiber-optic cable or other cables, regular and backup power supplies, and comparable equipment, regardless of technological configuration, and equipment associated with wireless communications. The term includes small wireless facilities. The term does not include:
a. The structure or improvements on, under, within, or adjacent to the structure on which the equipment is collocated;
b. Wireline backhaul facilities; or
c. Coaxial or fiber-optic cable that is between wireless structures or utility poles or that is otherwise not immediately adjacent to or directly associated with a particular antenna.
13. “Wireless infrastructure provider” means a person who has been certificated under chapter 364 to provide telecommunications service or under chapter 610 to provide cable or video services in this state, or that person’s affiliate, and who builds or installs wireless communication transmission equipment, wireless facilities, or wireless support structures but is not a wireless services provider.
14. “Wireless provider” means a wireless infrastructure provider or a wireless services provider.
15. “Wireless services” means any services provided using licensed or unlicensed spectrum, whether at a fixed location or mobile, using wireless facilities.
16. “Wireless services provider” means a person who provides wireless services.
17. “Wireless support structure” means a freestanding structure, such as a monopole, a guyed or self-supporting tower, or another existing or proposed structure designed to support or capable of supporting wireless facilities. The term does not include a utility pole, pedestal, or other support structure for ground-based equipment not mounted on a utility pole and less than 5 feet in height.
(c) Except as provided in this subsection, an authority may not prohibit, regulate, or charge for the collocation of small wireless facilities in the public rights-of-way or for the installation, maintenance, modification, operation, or replacement of utility poles used for the collocation of small wireless facilities in the public rights-of-way.
(d) An authority may require a registration process and permit fees in accordance with subsection (3). An authority shall accept applications for permits and shall process and issue permits subject to the following requirements:
1. An authority may not directly or indirectly require an applicant to perform services unrelated to the collocation for which approval is sought, such as in-kind contributions to the authority, including reserving fiber, conduit, or pole space for the authority.
2. An applicant may not be required to provide more information to obtain a permit than is necessary to demonstrate the applicant’s compliance with applicable codes for the placement of small wireless facilities in the locations identified in the application. An applicant may not be required to provide inventories, maps, or locations of communications facilities in the right-of-way other than as necessary to avoid interference with other at-grade or aerial facilities located at the specific location proposed for a small wireless facility or within 50 feet of such location.
3. An authority may not:
a. Require the placement of small wireless facilities on any specific utility pole or category of poles;
b. Require the placement of multiple antenna systems on a single utility pole;
c. Require a demonstration that collocation of a small wireless facility on an existing structure is not legally or technically possible as a condition for granting a permit for the collocation of a small wireless facility on a new utility pole except as provided in paragraph (i);
d. Require compliance with an authority’s provisions regarding placement of small wireless facilities or a new utility pole used to support a small wireless facility in rights-of-way under the control of the department unless the authority has received a delegation from the department for the location of the small wireless facility or utility pole, or require such compliance as a condition to receive a permit that is ancillary to the permit for collocation of a small wireless facility, including an electrical permit;
e. Require a meeting before filing an application;
f. Require direct or indirect public notification or a public meeting for the placement of communication facilities in the right-of-way;
g. Limit the size or configuration of a small wireless facility or any of its components, if the small wireless facility complies with the size limits in this subsection;
h. Prohibit the installation of a new utility pole used to support the collocation of a small wireless facility if the installation otherwise meets the requirements of this subsection; or
i. Require that any component of a small wireless facility be placed underground except as provided in paragraph (i).
4. Subject to paragraph (r), an authority may not limit the placement, by minimum separation distances, of small wireless facilities, utility poles on which small wireless facilities are or will be collocated, or other at-grade communications facilities. However, within 14 days after the date of filing the application, an authority may request that the proposed location of a small wireless facility be moved to another location in the right-of-way and placed on an alternative authority utility pole or support structure or placed on a new utility pole. The authority and the applicant may negotiate the alternative location, including any objective design standards and reasonable spacing requirements for ground-based equipment, for 30 days after the date of the request. At the conclusion of the negotiation period, if the alternative location is accepted by the applicant, the applicant must notify the authority of such acceptance and the application shall be deemed granted for any new location for which there is agreement and all other locations in the application. If an agreement is not reached, the applicant must notify the authority of such nonagreement and the authority must grant or deny the original application within 90 days after the date the application was filed. A request for an alternative location, an acceptance of an alternative location, or a rejection of an alternative location must be in writing and provided by electronic mail.
5. An authority shall limit the height of a small wireless facility to 10 feet above the utility pole or structure upon which the small wireless facility is to be collocated. Unless waived by an authority, the height for a new utility pole is limited to the tallest existing utility pole as of July 1, 2017, located in the same right-of-way, other than a utility pole for which a waiver has previously been granted, measured from grade in place within 500 feet of the proposed location of the small wireless facility. If there is no utility pole within 500 feet, the authority shall limit the height of the utility pole to 50 feet.
6. The installation by a communications services provider of a utility pole in the public rights-of-way, other than a utility pole used to support a small wireless facility, is subject to authority rules or regulations governing the placement of utility poles in the public rights-of-way.
7. Within 14 days after receiving an application, an authority must determine and notify the applicant by electronic mail as to whether the application is complete. If an application is deemed incomplete, the authority must specifically identify the missing information. An application is deemed complete if the authority fails to provide notification to the applicant within 14 days.
8. An application must be processed on a nondiscriminatory basis. A complete application is deemed approved if an authority fails to approve or deny the application within 60 days after receipt of the application. If an authority does not use the 30-day negotiation period provided in subparagraph 4., the parties may mutually agree to extend the 60-day application review period. The authority shall grant or deny the application at the end of the extended period. A permit issued pursuant to an approved application shall remain effective for 1 year unless extended by the authority.
9. An authority must notify the applicant of approval or denial by electronic mail. An authority shall approve a complete application unless it does not meet the authority’s applicable codes. If the application is denied, the authority must specify in writing the basis for denial, including the specific code provisions on which the denial was based, and send the documentation to the applicant by electronic mail on the day the authority denies the application. The applicant may cure the deficiencies identified by the authority and resubmit the application within 30 days after notice of the denial is sent to the applicant. The authority shall approve or deny the revised application within 30 days after receipt or the application is deemed approved. The review of a revised application is limited to the deficiencies cited in the denial. If an authority provides for administrative review of the denial of an application, the review must be complete and a written decision issued within 45 days after a written request for review is made. A denial must identify the specific code provisions on which the denial is based. If the administrative review is not complete within 45 days, the authority waives any claim regarding failure to exhaust administrative remedies in any judicial review of the denial of an application.
10. An applicant seeking to collocate small wireless facilities within the jurisdiction of a single authority may, at the applicant’s discretion, file a consolidated application and receive a single permit for the collocation of up to 30 small wireless facilities. If the application includes multiple small wireless facilities, an authority may separately address small wireless facility collocations for which incomplete information has been received or which are denied.
11. An authority may deny an application to collocate a small wireless facility or place a utility pole used to support a small wireless facility in the public rights-of-way if the proposed small wireless facility or utility pole used to support a small wireless facility:
a. Materially interferes with the safe operation of traffic control equipment.
b. Materially interferes with sight lines or clear zones for transportation, pedestrians, or public safety purposes.
c. Materially interferes with compliance with the Americans with Disabilities Act or similar federal or state standards regarding pedestrian access or movement.
d. Materially fails to comply with the 2017 edition of the Florida Department of Transportation Utility Accommodation Manual.
e. Fails to comply with applicable codes.
f. Fails to comply with objective design standards authorized under paragraph (r).
12. An authority may adopt by ordinance provisions for insurance coverage, indemnification, force majeure, abandonment, authority liability, or authority warranties. Such provisions must be reasonable and nondiscriminatory. An authority may require a construction bond to secure restoration of the postconstruction rights-of-way to the preconstruction condition. However, such bond must be time-limited to not more than 18 months after the construction to which the bond applies is completed. For any financial obligation required by an authority allowed under this section, the authority shall accept a letter of credit or similar financial instrument issued by any financial institution that is authorized to do business within the United States, provided that a claim against the financial instrument may be made by electronic means, including by facsimile. A provider of communications services may add an authority to any existing bond, insurance policy, or other relevant financial instrument, and the authority must accept such proof of coverage without any conditions other than consent to venue for purposes of any litigation to which the authority is a party. An authority may not require a communications services provider to indemnify it for liabilities not caused by the provider, including liabilities arising from the authority’s negligence, gross negligence, or willful conduct.
13. Collocation of a small wireless facility on an authority utility pole does not provide the basis for the imposition of an ad valorem tax on the authority utility pole.
14. An authority may reserve space on authority utility poles for future public safety uses. However, a reservation of space may not preclude collocation of a small wireless facility. If replacement of the authority utility pole is necessary to accommodate the collocation of the small wireless facility and the future public safety use, the pole replacement is subject to make-ready provisions and the replaced pole shall accommodate the future public safety use.
15. A structure granted a permit and installed pursuant to this subsection shall comply with chapter 333 and federal regulations pertaining to airport airspace protections.
(e) An authority may not require any permit or other approval or require fees or other charges, costs, or other exactions for:
1. Routine maintenance, the performance of service restoration work on existing facilities, or repair work, including, but not limited to, emergency repairs of existing facilities or extensions of such facilities for providing communications services to customers;
2. Replacement of existing wireless facilities with wireless facilities that are substantially similar or of the same or smaller size; or
3. Installation, placement, maintenance, or replacement of micro wireless facilities that are suspended on cables strung between existing utility poles in compliance with applicable codes by or for a communications services provider authorized to occupy the rights-of-way and who is remitting taxes under chapter 202. An authority may require an initial letter from or on behalf of such provider, which is effective upon filing, attesting that the micro wireless facility dimensions comply with the limits of this subsection. The authority may not require any additional filing or other information as long as the provider is deploying the same, a substantially similar, or a smaller size micro wireless facility equipment.
Notwithstanding this paragraph, an authority may require a right-of-way permit for work that involves excavation, closure of a sidewalk, or closure of a vehicular lane or parking lane, unless the provider is performing service restoration on an existing facility and the work is done in compliance with the 2017 edition of the Florida Department of Transportation Utility Accommodation Manual. An authority may require notice of such work within 30 days after restoration and may require an after-the-fact permit for work which would otherwise have required a permit.
(f) Collocation of small wireless facilities on authority utility poles is subject to the following requirements:
1. An authority may not enter into an exclusive arrangement with any person for the right to attach equipment to authority utility poles.
2. The rates and fees for collocations on authority utility poles must be nondiscriminatory, regardless of the services provided by the collocating person.
3. The rate to collocate small wireless facilities on an authority utility pole may not exceed $150 per pole annually.
4. Agreements between authorities and wireless providers that are in effect on July 1, 2017, and that relate to the collocation of small wireless facilities in the right-of-way, including the collocation of small wireless facilities on authority utility poles, remain in effect, subject to applicable termination provisions. The wireless provider may accept the rates, fees, and terms established under this subsection for small wireless facilities and utility poles that are the subject of an application submitted after the rates, fees, and terms become effective.
5. A person owning or controlling an authority utility pole shall offer rates, fees, and other terms that comply with this subsection. By the later of January 1, 2018, or 3 months after receiving a request to collocate its first small wireless facility on a utility pole owned or controlled by an authority, the person owning or controlling the authority utility pole shall make available, through ordinance or otherwise, rates, fees, and terms for the collocation of small wireless facilities on the authority utility pole which comply with this subsection.
a. The rates, fees, and terms must be nondiscriminatory and competitively neutral and must comply with this subsection.
b. For an authority utility pole that supports an aerial facility used to provide communications services or electric service, the parties shall comply with the process for make-ready work under 47 U.S.C. s. 224 and implementing regulations. The good faith estimate of the person owning or controlling the pole for any make-ready work necessary to enable the pole to support the requested collocation must include pole replacement if necessary.
c. For an authority utility pole that does not support an aerial facility used to provide communications services or electric service, the authority shall provide a good faith estimate for any make-ready work necessary to enable the pole to support the requested collocation, including necessary pole replacement, within 60 days after receipt of a complete application. Make-ready work, including any pole replacement, must be completed within 60 days after written acceptance of the good faith estimate by the applicant. Alternatively, an authority may require the applicant seeking to collocate a small wireless facility to provide a make-ready estimate at the applicant’s expense for the work necessary to support the small wireless facility, including pole replacement, and perform the make-ready work. If pole replacement is required, the scope of the make-ready estimate is limited to the design, fabrication, and installation of a utility pole that is substantially similar in color and composition. The authority may not condition or restrict the manner in which the applicant obtains, develops, or provides the estimate or conducts the make-ready work subject to usual construction restoration standards for work in the right-of-way. The replaced or altered utility pole shall remain the property of the authority.
d. An authority may not require more make-ready work than is required to meet applicable codes or industry standards. Fees for make-ready work may not include costs related to preexisting damage or prior noncompliance. Fees for make-ready work, including any pole replacement, may not exceed actual costs or the amount charged to communications services providers other than wireless services providers for similar work and may not include any consultant fee or expense.
(g) For any applications filed before the effective date of ordinances implementing this subsection, an authority may apply current ordinances relating to placement of communications facilities in the right-of-way related to registration, permitting, insurance coverage, indemnification, force majeure, abandonment, authority liability, or authority warranties. Permit application requirements and small wireless facility placement requirements, including utility pole height limits, that conflict with this subsection must be waived by the authority. An authority may not institute, either expressly or de facto, a moratorium, zoning-in-progress, or other mechanism that would prohibit or delay the filing, receiving, or processing of registrations, applications, or issuing of permits or other approvals for the collocation of small wireless facilities or the installation, modification, or replacement of utility poles used to support the collocation of small wireless facilities.
(h) Except as provided in this section or specifically required by state law, an authority may not adopt or enforce any regulation on the placement or operation of communications facilities in the rights-of-way by a provider authorized by state law to operate in the rights-of-way and may not regulate any communications services or impose or collect any tax, fee, or charge not specifically authorized under state law. This paragraph does not alter any law regarding an authority’s ability to regulate the relocation of facilities.
(i)1. In an area where an authority has required all public utility lines in the rights-of-way to be placed underground, a wireless provider must comply with written, objective, reasonable, and nondiscriminatory requirements that prohibit new utility poles used to support small wireless facilities if:
a. The authority, at least 90 days prior to the submission of an application, has required all public utility lines to be placed underground;
b. Structures that the authority allows to remain above ground are reasonably available to wireless providers for the collocation of small wireless facilities and may be replaced by a wireless provider to accommodate the collocation of small wireless facilities; and
c. A wireless provider may install a new utility pole in the designated area in the right-of-way that otherwise complies with this subsection and it is not reasonably able to provide wireless service by collocating on a remaining utility pole or other structure in the right-of-way.
2. For small wireless facilities installed before an authority adopts requirements that public utility lines be placed underground, an authority adopting such requirements must:
a. Allow a wireless provider to maintain the small wireless facilities in place subject to any applicable pole attachment agreement with the pole owner; or
b. Allow the wireless provider to replace the associated pole within 50 feet of the prior location in accordance with paragraph (r).
(j) A wireless infrastructure provider may apply to an authority to place utility poles in the public rights-of-way to support the collocation of small wireless facilities. The application must include an attestation that small wireless facilities will be collocated on the utility pole or structure and will be used by a wireless services provider to provide service within 9 months after the date the application is approved. The authority shall accept and process the application in accordance with subparagraph (d)6. and any applicable codes and other local codes governing the placement of utility poles in the public rights-of-way.
(k) This subsection does not limit a local government’s authority to enforce historic preservation zoning regulations consistent with the preservation of local zoning authority under 47 U.S.C. s. 332(c)(7), the requirements for facility modifications under 47 U.S.C. s. 1455(a), or the National Historic Preservation Act of 1966, as amended, and the regulations adopted to implement such laws. An authority may enforce local codes, administrative rules, or regulations adopted by ordinance in effect on April 1, 2017, which are applicable to a historic area designated by the state or authority. An authority may enforce pending local ordinances, administrative rules, or regulations applicable to a historic area designated by the state if the intent to adopt such changes has been publicly declared on or before April 1, 2017. An authority may waive any ordinances or other requirements that are subject to this paragraph.
(l) This subsection does not authorize a person to collocate or attach wireless facilities, including any antenna, micro wireless facility, or small wireless facility, on a privately owned utility pole, a utility pole owned by an electric cooperative or a municipal electric utility, a privately owned wireless support structure, or other private property without the consent of the property owner.
(m) The approval of the installation, placement, maintenance, or operation of a small wireless facility pursuant to this subsection does not authorize the provision of any voice, data, or video communications services or the installation, placement, maintenance, or operation of any communications facilities other than small wireless facilities in the right-of-way.
(n) This subsection does not affect provisions relating to pass-through providers in subsection (6).
(o) This subsection does not authorize a person to collocate or attach small wireless facilities or micro wireless facilities on a utility pole, unless otherwise permitted by federal law, or erect a wireless support structure in the right-of-way located within a retirement community that:
1. Is deed restricted as housing for older persons as defined in s. 760.29(4)(b);
2. Has more than 5,000 residents; and
3. Has underground utilities for electric transmission or distribution.
This paragraph does not apply to the installation, placement, maintenance, or replacement of micro wireless facilities on any existing and duly authorized aerial communications facilities, provided that once aerial facilities are converted to underground facilities, any such collocation or construction shall be only as provided by the municipality’s underground utilities ordinance.
(p) This subsection does not authorize a person to collocate or attach small wireless facilities or micro wireless facilities on a utility pole, unless otherwise permitted by federal law, or erect a wireless support structure in the right-of-way located within a municipality that:
1. Is located on a coastal barrier island as defined in s. 161.053(1)(b)3.;
2. Has a land area of less than 5 square miles;
3. Has fewer than 10,000 residents; and
4. Has, before July 1, 2017, received referendum approval to issue debt to finance municipal-wide undergrounding of its utilities for electric transmission or distribution.
This paragraph does not apply to the installation, placement, maintenance, or replacement of micro wireless facilities on any existing and duly authorized aerial communications facilities, provided that once aerial facilities are converted to underground facilities, any such collocation or construction shall be only as provided by the municipality’s underground utilities ordinance.
(q) This subsection does not authorize a person to collocate small wireless facilities or micro wireless facilities on an authority utility pole or erect a wireless support structure in a location subject to covenants, conditions, restrictions, articles of incorporation, and bylaws of a homeowners’ association. This paragraph does not apply to the installation, placement, maintenance, or replacement of micro wireless facilities on any existing and duly authorized aerial communications facilities.
(r) An authority may require wireless providers to comply with objective design standards adopted by ordinance. The ordinance may only require:
1. A new utility pole that replaces an existing utility pole to be of substantially similar design, material, and color;
2. Reasonable spacing requirements concerning the location of a ground-mounted component of a small wireless facility which does not exceed 15 feet from the associated support structure; or
3. A small wireless facility to meet reasonable location context, color, camouflage, and concealment requirements, subject to the limitations in this subsection; and
4. A new utility pole used to support a small wireless facility to meet reasonable location context, color, and material of the predominant utility pole type at the proposed location of the new utility pole.
Such design standards under this paragraph may be waived by the authority upon a showing that the design standards are not reasonably compatible for the particular location of a small wireless facility or utility pole or are technically infeasible or that the design standards impose an excessive expense. The waiver must be granted or denied within 45 days after the date of the request.
(8)(a) Any person aggrieved by a violation of this section may bring a civil action in a United States District Court or in any other court of competent jurisdiction.
(b) The court may:
1. Grant temporary or permanent injunctions on terms as it may deem reasonable to prevent or restrain violations of this section; and
2. Direct the recovery of full costs, including awarding reasonable attorney fees, to the party who prevails.
(9) All work in the authority’s rights-of-way under this section must comply with the 2017 edition of the Florida Department of Transportation Utility Accommodation Manual.
History.—s. 127, ch. 29965, 1955; s. 1, ch. 63-279; s. 1, ch. 65-52; ss. 23, 35, ch. 69-106; s. 141, ch. 84-309; s. 8, ch. 85-174; s. 8, ch. 86-155; ss. 2, 21, ch. 88-168; s. 8, ch. 89-232; s. 41, ch. 91-221; s. 26, ch. 94-237; s. 1, ch. 98-147; s. 2, ch. 99-354; ss. 50, 51, 58, 59, ch. 2000-260; ss. 34, 35, 38, ch. 2001-140; s. 81, ch. 2002-20; s. 6, ch. 2002-48; s. 57, ch. 2003-286; s. 13, ch. 2004-366; s. 6, ch. 2005-171; s. 10, ch. 2006-138; s. 5, ch. 2007-29; s. 29, ch. 2008-227; s. 22, ch. 2010-225; s. 2, ch. 2016-44; s. 5, ch. 2017-42; s. 1, ch. 2017-136; s. 15, ch. 2019-42; s. 2, ch. 2019-131; s. 1, ch. 2020-21; s. 25, ch. 2022-4.
Note.—Former s. 338.17.
337.402 Damage to public road caused by utility.—When any public road or publicly owned rail corridor is damaged or impaired in any way because of the installation, inspection, or repair of a utility located on such road or publicly owned rail corridor, the owner of the utility shall, at his or her own expense, restore the road or publicly owned rail corridor to its original condition before such damage. If the owner fails to make such restoration, the authority is authorized to do so and charge the cost thereof against the owner under the provisions of s. 337.404.
History.—s. 128, ch. 29965, 1955; s. 142, ch. 84-309; s. 27, ch. 94-237; s. 969, ch. 95-148.
Note.—Former s. 338.18.
337.403 Interference caused by utility; expenses.—
(1) If a utility that is placed upon, under, over, or within the right-of-way limits of any public road or publicly owned rail corridor is found by the authority to be unreasonably interfering in any way with the convenient, safe, or continuous use, or the maintenance, improvement, extension, or expansion, of such public road or publicly owned rail corridor, the utility owner shall, upon 30 days’ written notice to the utility or its agent by the authority, initiate the work necessary to alleviate the interference at its own expense except as provided in paragraphs (a)-(j). The work must be completed within such reasonable time as stated in the notice or such time as agreed to by the authority and the utility owner.
(a) If the relocation of utility facilities, as referred to in s. 111 of the Federal-Aid Highway Act of 1956, Pub. L. No. 84-627, is necessitated by the construction of a project on the federal-aid interstate system, including extensions thereof within urban areas, and the cost of the project is eligible and approved for reimbursement by the Federal Government to the extent of 90 percent or more under the Federal-Aid Highway Act, or any amendment thereof, then in that event the utility owning or operating such facilities shall perform any necessary work upon notice from the department, and the state shall pay the entire expense properly attributable to such work after deducting therefrom any increase in the value of a new facility and any salvage value derived from an old facility.
(b) When a joint agreement between the department and the utility is executed for utility work to be accomplished as part of a contract for construction of a transportation facility, the department may participate in those utility work costs that exceed the department’s official estimate of the cost of the work by more than 10 percent. The amount of such participation is limited to the difference between the official estimate of all the work in the joint agreement plus 10 percent and the amount awarded for this work in the construction contract for such work. The department may not participate in any utility work costs that occur as a result of changes or additions during the course of the contract.
(c) When an agreement between the department and utility is executed for utility work to be accomplished in advance of a contract for construction of a transportation facility, the department may participate in the cost of clearing and grubbing necessary to perform such work.
(d) If the utility facility was initially installed to exclusively serve the authority or its tenants, or both, the authority shall bear the costs of the utility work. However, the authority is not responsible for the cost of utility work related to any subsequent additions to that facility for the purpose of serving others. For a county or municipality, if such utility facility was installed in the right-of-way as a means to serve a county or municipal facility on a parcel of property adjacent to the right-of-way and if the intended use of the county or municipal facility is for a use other than transportation purposes, the obligation of the county or municipality to bear the costs of the utility work shall extend only to utility work on the parcel of property on which the facility of the county or municipality originally served by the utility facility is located.
(e) If, under an agreement between a utility and the authority entered into after July 1, 2009, the utility conveys, subordinates, or relinquishes a compensable property right to the authority for the purpose of accommodating the acquisition or use of the right-of-way by the authority, without the agreement expressly addressing future responsibility for the cost of necessary utility work, the authority shall bear the cost of removal or relocation. This paragraph does not impair or restrict, and may not be used to interpret, the terms of any such agreement entered into before July 1, 2009.
(f) If the utility is an electric facility being relocated underground in order to enhance vehicular, bicycle, and pedestrian safety and in which ownership of the electric facility to be placed underground has been transferred from a private to a public utility within the past 5 years, the department shall incur all costs of the necessary utility work.
(g) An authority may bear the costs of utility work required to eliminate an unreasonable interference when the utility is not able to establish that it has a compensable property right in the particular property where the utility is located if:
1. The utility was physically located on the particular property before the authority acquired rights in the property;
2. The utility demonstrates that it has a compensable property right in adjacent properties along the alignment of the utility or, after due diligence, certifies that the utility does not have evidence to prove or disprove that it has a compensable property right in the particular property where the utility is located; and
3. The information available to the authority does not establish the relative priorities of the authority’s and the utility’s interests in the particular property.
(h) If a municipally owned utility or county-owned utility is located in a rural area of opportunity, as defined in s. 288.0656(2), and the department determines that the utility is unable, and will not be able within the next 10 years, to pay for the cost of utility work necessitated by a department project on the State Highway System, the department may pay, in whole or in part, the cost of such utility work performed by the department or its contractor.
(i) If the relocation of utility facilities is necessitated by the construction of a commuter rail service project or an intercity passenger rail service project and the cost of the project is eligible and approved for reimbursement by the Federal Government, then in that event the utility owning or operating such facilities located by permit on a department-owned rail corridor shall perform any necessary utility relocation work upon notice from the department, and the department shall pay the expense properly attributable to such utility relocation work in the same proportion as federal funds are expended on the commuter rail service project or an intercity passenger rail service project after deducting therefrom any increase in the value of a new facility and any salvage value derived from an old facility. In no event shall the state be required to use state dollars for such utility relocation work. This paragraph does not apply to any phase of the Central Florida Commuter Rail project, known as SunRail.
(j) If a utility is lawfully located within an existing and valid utility easement granted by recorded plat, regardless of whether such land was subsequently acquired by the authority by dedication, transfer of fee, or otherwise, the authority must bear the cost of the utility work required to eliminate an unreasonable interference. The authority shall pay the entire expense properly attributable to such work after deducting any increase in the value of a new facility and any salvage value derived from an old facility.
(2) If such utility work is incidental to work to be done on such road or publicly owned rail corridor, the notice shall be given at the same time the contract for the work is advertised for bids, or no less than 30 days before the commencement of such work by the authority, whichever occurs later.
(3) Whenever a notice from the authority requires such utility work and the owner thereof fails to perform the work at his or her own expense within the time stated in the notice or such other time as agreed to by the authority and the utility owner, the authority shall proceed to cause the utility work to be performed. The expense thereby incurred shall be paid out of any money available therefor, and such expense shall, except as provided in subsection (1), be charged against the owner and levied and collected and paid into the fund from which the expense of such relocation was paid.
History.—s. 129, ch. 29965, 1955; s. 1, ch. 57-135; s. 1, ch. 57-1978; ss. 23, 35, ch. 69-106; s. 143, ch. 84-309; s. 12, ch. 87-100; s. 28, ch. 94-237; s. 970, ch. 95-148; s. 25, ch. 99-385; s. 10, ch. 2009-85; s. 35, ch. 2012-174; s. 5, ch. 2014-169; s. 24, ch. 2015-2; s. 3, ch. 2016-44.
Note.—Former s. 338.19.
337.404 Removal or relocation of utility facilities; notice and order; court review.—
(1) Whenever it becomes necessary for the authority to perform utility work as provided in s. 337.403, the owner of the utility or the owner’s chief agent shall be given notice that the authority will perform such work and, after the work is completed, shall be given an order requiring the payment of the cost thereof and a reasonable time, which may not be less than 20 or more than 30 days, in which to appear before the authority to contest the reasonableness of the order. Should the owner or the owner’s representative not appear, the determination of the cost to the owner shall be final. Authorities considered agencies for the purposes of chapter 120 shall adjudicate removal or relocation of utilities pursuant to chapter 120.
(2) A final order of the authority shall constitute a lien on any property of the owner and may be enforced by filing an authenticated copy of the order in the office of the clerk of the circuit court of the county wherein the owner’s property is located.
(3) The owner may obtain judicial review of the final order of the authority within the time and in the manner provided by the Florida Rules of Appellate Procedure by filing in the circuit court of the county in which the utility was relocated a petition for a writ of certiorari in the manner prescribed by said rules or in the manner provided by chapter 120 when the respondent is an agency for purposes of chapter 120.
History.—s. 130, ch. 29965, 1955; s. 16, ch. 63-512; s. 1, ch. 69-267; ss. 23, 35, ch. 69-106; s. 56, ch. 78-95; s. 144, ch. 84-309; s. 500, ch. 95-148; s. 36, ch. 2012-174.
Note.—Former s. 338.20.
337.405 Trees or other vegetation within rights-of-way of State Highway System or publicly owned rail corridors; removal or damage; penalty.—
(1) The removal, cutting, marring, defacing, or destruction of any trees or other vegetation, either by direct personal action or by causing any other person to take such action, within the rights-of-way of roads located on the State Highway System or within publicly owned rail corridors is prohibited unless prior written permission to remove or cut such trees or other vegetation has been granted by the department, except where normal tree trimming is required to ensure the safe operation of utility facilities and such tree trimming is performed in accordance with the provisions of its utility accommodations guide, and any subsequent amendments thereto. The department shall adopt rules for the implementation of this section to achieve protection of vegetation while at the same time assuring safe utility operations.
(2) Any person who violates the provisions of this section is guilty of a misdemeanor of the second degree, punishable as provided in s. 775.082 or s. 775.083.
History.—s. 156, ch. 29965, 1955; ss. 23, 35, ch. 69-106; s. 238, ch. 71-136; s. 46, ch. 84-309; s. 29, ch. 94-237.
Note.—Former s. 339.25.
337.406 Unlawful use of state transportation facility right-of-way; penalties.—
(1) Except when leased as provided in s. 337.25(5) or otherwise authorized by the rules of the department, it is unlawful to make any use of the right-of-way of any state transportation facility, including appendages thereto, outside of an incorporated municipality in any manner that interferes with the safe and efficient movement of people and property from place to place on the transportation facility. Failure to prohibit the use of right-of-way in this manner will endanger the health, safety, and general welfare of the public by causing distractions to motorists, unsafe pedestrian movement within travel lanes, sudden stoppage or slowdown of traffic, rapid lane changing and other dangerous traffic movement, increased vehicular accidents, and motorist injuries and fatalities. Such prohibited uses include, but are not limited to, the free distribution or sale, or display or solicitation for free distribution or sale, of any merchandise, goods, property or services; the solicitation for charitable purposes; the servicing or repairing of any vehicle, except the rendering of emergency service; the storage of vehicles being serviced or repaired on abutting property or elsewhere; and the display of advertising of any sort, except that any portion of a state transportation facility may be used for an art festival, parade, fair, or other special event if permitted by the appropriate local governmental entity. Local government entities may issue permits of limited duration for the temporary use of the right-of-way of a state transportation facility for any of these prohibited uses if it is determined that the use will not interfere with the safe and efficient movement of traffic and the use will cause no danger to the public. The permitting authority granted in this subsection shall be exercised by the municipality within incorporated municipalities and by the county outside an incorporated municipality. Before a road on the State Highway System may be temporarily closed for a special event, the local governmental entity which permits the special event to take place must determine that the temporary closure of the road is necessary and must obtain the prior written approval for the temporary road closure from the department. Nothing in this subsection shall be construed to authorize such activities on any limited access highway. Local governmental entities may, within their respective jurisdictions, initiate enforcement action by the appropriate code enforcement authority or law enforcement authority for a violation of this section.
(2) Persons holding valid peddlers’ licenses issued by appropriate governmental entities may make sales from vehicles standing on the right-of-way to occupants of abutting property only.
(3) The Department of Highway Safety and Motor Vehicles and other law enforcement agencies are authorized and directed to enforce this statute.
(4) Camping is prohibited on any portion of the right-of-way of the State Highway System that is within 100 feet of a bridge, causeway, overpass, or ramp.
(5) The violation of any provision of this section or any rule promulgated by the department pursuant to this section constitutes a misdemeanor of the second degree, punishable as provided in s. 775.082 or s. 775.083, and each day a violation continues to exist constitutes a separate offense.
History.—s. 1, ch. 73-188; s. 1, ch. 79-30; s. 206, ch. 81-259; s. 168, ch. 84-309; s. 3, ch. 86-37; s. 3, ch. 87-266; s. 25, ch. 88-168; s. 9, ch. 90-227; s. 43, ch. 95-257; s. 10, ch. 2005-281; s. 23, ch. 2010-225.
Note.—Former s. 339.301.
337.4061 Definitions; unlawful use of state-maintained road right-of-way by nonfranchised cable and video services.—
(1) As used in this section, the term:
(a) “Cable service” means:
1. The one-way transmission to subscribers of video programming or any other programming service; and
2. Subscriber interaction, if any, which is required for the selection or use of such video programming or other programming service.
(b) “Cable system” means a facility, consisting of a set of closed transmission paths and associated signal generation, reception, and control equipment that is designed to provide cable service which includes video programming and which is provided to multiple subscribers within a community, but such term does not include:
1. A facility that serves only to retransmit the television signals of one or more television broadcast stations;
2. A facility that serves only subscribers in one or more multiple-unit dwellings under common ownership, control, or management, unless such facility or facilities use any public right-of-way;
3. A facility that serves subscribers without using any public right-of-way.
4. A facility of a common carrier that is subject, in whole or in part, to the provisions of Title II of the federal Communications Act of 1934, except such facility shall be considered a cable system other than for purposes of 47 U.S.C. s. 541(c) to the extent such facility is used in the transmission of video programming directly to subscribers, unless the extent of such use is solely to provide interactive on-demand services;
5. Any facilities of any electric utility used solely for operating its electric utility systems; or
6. An open video system that complies with 47 U.S.C. s. 573.
(c) “Franchise” means an initial authorization or renewal thereof issued by a franchising authority, whether such authorization is designated as a franchise, permit, license, resolution, contract, certificate, agreement, or otherwise, which authorizes the construction or operation of a cable system or video service provider network facilities.
(d) “Franchising authority” means any governmental entity empowered by federal, state, or local law to grant a franchise.
(e) “Person” means an individual, partnership, association, joint stock company, trust, corporation, or governmental entity.
(f) “Video programming” means programming provided by or generally considered comparable to programming provided by a television broadcast station or cable system.
(g) “Video service” has the same meaning as that provided in s. 610.103.
(2) It is unlawful to use the right-of-way of any state-maintained road, including appendages thereto, and also including, but not limited to, rest areas, wayside parks, boat-launching ramps, weigh stations, and scenic easements, to provide for cable or video service over facilities within a geographic area subject to a valid existing franchise for cable or video service, unless the cable or video service provider using such right-of-way holds a franchise from a franchise authority for the area in which the right-of-way is located.
(3) A violation of this section shall be deemed a violation of s. 337.406.
History.—s. 2, ch. 87-266; s. 6, ch. 2007-29.
337.407 Regulation of signs and lights within rights-of-way.—
(1) No person shall erect any sign, as defined in chapter 479, or light within the right-of-way limits of any road on the interstate highway system, the federal-aid primary highway system, the State Highway System, or the State Park Road System; however, the department is authorized to adopt rules concerning the placement of signs, canopies, and other overhanging encroachments along and over any state roads which are within municipalities, or which are of curb-and-gutter construction outside municipalities, provided no supports are located within the rights-of-way.
(2) The department has the authority to direct removal of any sign erected in violation of subsection (1), in accordance with the provisions of chapter 479.
(3) The department may not authorize the erection of signs where such signs are prohibited by the local governmental entity having jurisdiction.
History.—s. 37, ch. 29965, 1955; s. 1, ch. 63-501; s. 5, ch. 67-461; ss. 23, 35, ch. 69-106; s. 1, ch. 71-38; s. 1, ch. 74-79; s. 9, ch. 78-412; s. 1, ch. 80-246; s. 49, ch. 84-309; s. 20, ch. 85-180; s. 160, ch. 92-152; ss. 30, 62, ch. 94-237; s. 122, ch. 99-13; s. 87, ch. 99-385.
Note.—Former s. 335.13.
337.408 Regulation of bus stops, benches, transit shelters, street light poles, waste disposal receptacles, and modular news racks within rights-of-way.—
(1) Benches or transit shelters, including advertising displayed on benches or transit shelters, may be installed within the right-of-way limits of any municipal, county, or state road, except a limited access highway, provided that such benches or transit shelters are for the comfort or convenience of the general public or are at designated stops on official bus routes and provided that written authorization has been given to a qualified private supplier of such service by the municipal government within whose incorporated limits such benches or transit shelters are installed or by the county government within whose unincorporated limits such benches or transit shelters are installed. A municipality or county may authorize the installation, without public bid, of benches and transit shelters together with advertising displayed thereon within the right-of-way limits of such roads. All installations shall be in compliance with all applicable laws and rules, including, without limitation, the Americans with Disabilities Act. Municipalities and counties that authorize or have authorized a bench or transit shelter to be installed within the right-of-way limits of any road on the State Highway System shall be responsible for ensuring that the bench or transit shelter complies with all applicable laws and rules, including, without limitation, the Americans with Disabilities Act, or shall remove the bench or transit shelter. The department shall have no liability for any claims, losses, costs, charges, expenses, damages, liabilities, attorney fees, or court costs relating to the installation, removal, or relocation of any benches or transit shelters authorized by a municipality or county. On and after July 1, 2012, a municipality or county that authorizes a bench or transit shelter to be installed within the right-of-way limits of any road on the State Highway System must require the qualified private supplier, or any other person under contract to install the bench or transit shelter, to indemnify, defend, and hold harmless the department from any suits, actions, proceedings, claims, losses, costs, charges, expenses, damages, liabilities, attorney fees, and court costs relating to the installation, removal, or relocation of such installations, and shall annually certify to the department in a notarized signed statement that this requirement has been met. The certification shall include the name and address of each person responsible for indemnifying the department for an authorized installation. Municipalities and counties that have authorized the installation of benches or transit shelters within the right-of-way limits of any road on the State Highway System must remove or relocate, or cause the removal or relocation of, the installation at no cost to the department within 60 days after written notice by the department that the installation is unreasonably interfering in any way with the convenient, safe, or continuous use of or the maintenance, improvement, extension, or expansion of the State Highway System road. Any contract for the installation of benches or transit shelters or advertising on benches or transit shelters which was entered into before April 8, 1992, without public bidding is ratified and affirmed. Such benches or transit shelters may not interfere with right-of-way preservation and maintenance. Any bench or transit shelter located on a sidewalk within the right-of-way limits of any road on the State Highway System or the county road system shall be located so as to leave at least 36 inches of clearance for pedestrians and persons in wheelchairs. Such clearance shall be measured in a direction perpendicular to the centerline of the road.
(2) Waste disposal receptacles of less than 110 gallons in capacity, including advertising displayed on such waste disposal receptacles, may be installed within the right-of-way limits of any municipal, county, or state road, except a limited access highway, provided that written authorization has been given to a qualified private supplier of such service by the appropriate municipal or county government. A municipality or county may authorize the installation, without public bid, of waste disposal receptacles together with advertising displayed thereon within the right-of-way limits of such roads. Such waste disposal receptacles may not interfere with right-of-way preservation and maintenance.
(3) Modular news racks, including advertising thereon, may be located within the right-of-way limits of any municipal, county, or state road, except a limited access highway, if the municipal government within whose incorporated limits such racks are installed or the county government within whose unincorporated limits such racks are installed has passed an ordinance regulating the placement of modular news racks within the right-of-way and has authorized a qualified private supplier of modular news racks to provide such service. The modular news rack or advertising thereon may not exceed a height of 105 inches or a total advertising space of 56 square feet. No later than 45 days before installation of modular news racks, the private supplier must provide a map of proposed locations and typical installation plans to the department for approval. If the department does not respond within 45 days after receipt of the submitted plans, installation may proceed.
(4) The department has the authority to direct the immediate relocation or removal of any bus stop, bench, transit shelter, waste disposal receptacle, public pay telephone, or modular news rack that endangers life or property or that is otherwise not in compliance with applicable laws and rules, except that transit bus benches that were placed in service before April 1, 1992, are not required to comply with bench size and advertising display size requirements established by the department before March 1, 1992. The department may adopt rules relating to the regulation of bench size and advertising display size requirements. If a municipality or county within which a bench is to be located has adopted an ordinance or other applicable regulation that establishes bench size or advertising display sign requirements different from requirements specified in department rule, the local government requirement applies within the respective municipality or county. Placement of any bench or advertising display on the National Highway System under a local ordinance or regulation adopted under this subsection is subject to approval of the Federal Highway Administration.
(5) A bus stop, bench, transit shelter, waste disposal receptacle, public pay telephone, or modular news rack, or advertising thereon, may not be erected or placed on the right-of-way of any road in a manner that conflicts with the requirements of federal law, regulations, or safety standards, thereby causing the state or any political subdivision the loss of federal funds. Competition among persons seeking to provide bus stop, bench, transit shelter, waste disposal receptacle, public pay telephone, or modular news rack services or advertising on such benches, shelters, receptacles, public pay telephone, or news racks may be regulated, restricted, or denied by the appropriate local government entity consistent with this section.
(6) Street light poles, including attached public service messages and advertisements, may be located within the right-of-way limits of municipal and county roads in the same manner as benches, transit shelters, waste disposal receptacles, and modular news racks as provided in this section and in accordance with municipal and county ordinances. Public service messages and advertisements may be installed on street light poles on roads on the State Highway System in accordance with height, size, setback, spacing distance, duration of display, safety, traffic control, and permitting requirements established by administrative rule of the Department of Transportation. Public service messages and advertisements shall be subject to bilateral agreements, where applicable, to be negotiated with the owner of the street light poles, which shall consider, among other things, power source rates, design, safety, operational and maintenance concerns, and other matters of public importance. For the purposes of this section, the term “street light poles” does not include electric transmission or distribution poles. The department shall have authority to adopt rules pursuant to ss. 120.536(1) and 120.54 to implement the provisions of this section. No advertising on light poles shall be permitted on the Interstate Highway System. No permanent structures carrying advertisements attached to light poles shall be permitted on the National Highway System.
(7) A public pay telephone, including advertising displayed thereon, may be installed within the right-of-way limits of any municipal, county, or state road, except on a limited access highway, if the pay telephone is installed by a provider duly authorized and regulated by the Public Service Commission under s. 364.3375, if the pay telephone is operated in accordance with all applicable state and federal telecommunications regulations, and if written authorization has been given to a public pay telephone provider by the appropriate municipal or county government. Each advertisement must be limited to a size no greater than 8 square feet, and a public pay telephone booth may not display more than three advertisements at any given time. An advertisement is not allowed on public pay telephones located in rest areas, welcome centers, or other such facilities located on an interstate highway.
(8) Wherever the provisions of this section are inconsistent with other provisions of this chapter or with the provisions of chapter 125, chapter 335, chapter 336, or chapter 479, the provisions of this section shall prevail.
History.—s. 21, ch. 85-180; s. 61, ch. 94-237; s. 30, ch. 95-257; s. 63, ch. 96-323; s. 82, ch. 2002-20; s. 22, ch. 2004-366; s. 11, ch. 2009-85; s. 37, ch. 2012-174; s. 13, ch. 2023-197.
337.409 Willfully or maliciously removing, damaging, destroying, altering, or appropriating benches, transit shelters, waste receptacles, or advertising displayed thereon; penalty.—Any person who willfully or maliciously removes, damages, destroys, tampers with or alters in any way a bench, transit shelter, or waste receptacle, or advertising displayed thereon, when such structure and display has been installed and maintained pursuant to the provisions of s. 337.408, or any person who in any manner appropriates to her or his own use or to the use of another by painting, printing, placing, or affixing any advertisement or similar material upon any such structure, or upon advertising displayed thereon, shall be guilty of a misdemeanor of the second degree, punishable as provided in s. 775.082 or s. 775.083.
History.—s. 31, ch. 95-257; s. 14, ch. 97-96.